Cross references. —

For constitutional provision that the legislature shall not pass local or special laws authorizing the creation, extension or impairing of liens, see art. 3, § 27, Wyo. Const.

As to lien of judgment and enforcement by execution, see §§ 1-17-301 to 1-17-345 .

As to liens for delinquent contributions under unemployment compensation, see § 27-3-510 .

For provision that a mortgage or other specific lien on real property shall take precedence over lien of taxes levied against any other property and the property subject to such lien, see § 34-2-124 .

As to secured transactions generally, see §§ 34.1-9-101 to 34.1-9-709.

As to lien upon reservoirs, irrigation systems and ditches, see § 36-7-326 .

As to liens in connection with water rights relative to Carey Act lands, see §§ 36-7-501 to 36-7-510 .

As to right of laborers, mechanics, farmers and other persons performing work or labor, or furnishing materials, etc., with reference to railroad construction, to file verified statement of account with railroad and collect the same from contractor through railroad, see §§ 37-9-602 , 37-9-603 .

Revision of title. —

Sections 1 and 2, ch. 17, Laws 1981, Sp. Sess., revised this title, creating §§ 29-1-201 , 29-1-304 through 20-1-309 and 29-7-301 , and amending and renumbering former W.S. 1977, §§ 29-1-101 through 29-7-106 as §§ 29-1-101 , 29-1-102 , 29-1-301 through 29-1-303 , 29-2-101 through 29-7-207 . No detailed explanation of the changes made by ch. 17, Laws 1981, Sp. Sess. have been attempted, but, where appropriate, historical citations to former provisions have been added to corresponding sections in this title, and annotations from cases decided under former provisions have been placed under comparable sections in this title where it was felt they would be helpful. See the tables of comparative sections in Volume 11.

Chapter 1 General Provisions

Applied in

Dewey v. Wentland, 2002 WY 2, 38 P.3d 402, 2002 Wyo. LEXIS 2 (Wyo. 2002).

Am. Jur. 2d, ALR and C.J.S. references. —

7 Am. Jur. 2d Attorneys at Law §§ 333 to 369; 51 Am. Jur. 2d Liens § 1 et seq.; 53 Am. Jur. 2d Marshaling Assets §§ 1 to 19, 24 to 28, 43 to 54.

Right to require security as condition of cancelling lien of record or recording payment, 2 ALR2d 1064.

Bank's lien upon commercial paper delivered to it by debtor for collection, 22 ALR2d 478.

Priority as between lien for repairs and the like, and right of seller under conditional sales contract, 36 ALR2d 198.

Liens for severance or dismissal pay provided for by employment contract or collective labor agreement, 40 ALR2d 1044.

Lien for storage of motor vehicle, 48 ALR2d 894.

Lien for improvements made or placed on premises of another by mistake, 57 ALR2d 263.

Decree for periodical payments for alimony or support as a lien or the subject of a declaration of lien, 59 ALR2d 656.

Accountant's right to lien upon client's books and records in former's possession, 76 ALR2d 1322.

Construction, operation and effect of statute giving hospital lien against recovery from tort feasor causing patient's injuries, 25 ALR3d 858.

Surveyor's work as giving rise to right to mechanic's lien, 35 ALR3d 1391.

Doctrine of marshaling assets where the two funds covered by the paramount lien are subject respectively to subordinate liens in favor of different creditors, 76 ALR3d 326.

Lien for towing or storage, ordered by public officer, of motor vehicle, 85 ALR3d 199.

Liability to pay for allegedly unauthorized repairs to motor vehicle, 5 ALR4th 311.

Construction, operation and effect of statute giving hospital lien against recovery from tortfeasor causing patient's injuries, 16 ALR5th 262.

Physicians' and surgeons' liens, 39 ALR5th 787.

Modern views as to validity, under federal constitution, of state prejudgment attachment, garnishment and replevin procedures, distraint procedures under landlord's or innkeeper's lien statutes and like procedures authorizing summary seizure of property, 18 ALR Fed 223.

Right of mortgagee and/or lienor to compensation when property subject to mortgage and/or lien is taken by federal governmental forfeiture based on criminal acts of owner, 136 ALR Fed 593.

Article 1. General Provisions

Editor's notes. —

Laws 2010, ch. 92, § 4, provides: “The provisions of this act shall apply to all projects commenced on or after July 1, 2011. Any projects commenced prior to July 1, 2011, shall be governed by the lien procedures in title 29 that existed prior to July 1, 2011.”

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

§ 29-1-101. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from C.L. 1876, ch. 113, Part V, § 6, related to lien of state on realty of debtor.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-102. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from C.L. 1876, ch. 6, § 8, related to lien of attorneys on papers and monies of clients.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-103. Short title.

W.S. 29-1-103 through 29-10-106 shall be known and may be cited as the “Revised Wyoming Statutory Lien Act”.

History. Laws 2010, ch. 92, § 1.

§ 29-1-104. Other lien statutes and legal processes not affected by this act.

  1. Unless other statutes relating to liens specifically provide that the procedures specified in chapter 1, 2, 9 or 10 of this act apply, this act is supplemental to and does not supersede any other lien statutes contained in chapters 3 through 8 of this act nor other lien statutes nor other statutes relating in any way to liens currently existing related to other types of property or other subject matters.
  2. Nothing in this act shall affect or abridge:
    1. A right of setoff;
    2. The right to file legal action based on equitable principles, including unjust enrichment, quantum meruit and other equitable doctrines; or
    3. The right to enforce a lien otherwise created by contract.

History. Laws 2010, ch. 92, § 1.

Stated in

Bd. of Prof'l Responsibility v. Casper, 2014 WY 22, 2014 Wyo. LEXIS 27 (Feb 19, 2014).

Article 2. Construction

§ 29-1-201. Definitions; agency relationships presumed.

  1. Except as otherwise provided, as used in this act:
    1. “Contractor” means:
      1. A person employed by and contracting with an owner to improve an owner’s property including:
        1. An architect;
        2. A professional engineer; and
        3. A surveyor.
    2. “Furnish” includes selling or renting;
    3. “Improve or improvement” means:
      1. Demolition, erection, alteration or repair of any property for its permanent benefit;
      2. Any work performed or material furnished for the permanent change of any real property; and
      3. Materials manufactured pursuant to contract.
    4. “Lien claimant” means any person who claims a lien under this act pursuant to a contract for improvement of property entered into by an owner of the property;
    5. “Owner” means:
      1. With respect to construction liens: any person with a legal or equitable interest in the property to be changed, altered or improved, for whose use or benefit any improvement shall be made or any materials furnished;
      2. With respect to mines, quarries, oil, gas or other wells: a person holding any interest in the legal or equitable title, or both, to any leasehold for oil or gas purposes and purchasers under executory contract, receivers and trustees;
      3. With respect to ditches, canals and reservoirs: a person holding any interest in the legal or equitable title to any ditch, canal or reservoir including rights-of-way, water permits, ditch rights and related easements of any type or kind. “Owner” includes purchasers under executory contract, receivers and trustees.
    6. “Subcontractor” means a person, other than a contractor performing work for a contractor or subcontractor under contract;
    7. “Work” shall be as requested, authorized or ratified under contract;
    8. “Material” means:
      1. Component parts incorporated into the project;
      2. Equipment and machinery, whether or not incorporated into the project; and
      3. Fuel and lubricants consumed in a project.
    9. “Materialman” means a person other than a contractor who furnishes material to, but does not perform work for, an owner, a contractor or subcontractor under contract;
    10. “Property” means real property, personal property, or both;
    11. “Real property” means all interests in real property, including but not limited to, the fee estate, leasehold interests, easements and rights of way;
    12. “Send” or “sent” means, in connection with any writing or written notice, to deposit in the mail or deliver for transmission by any other usual means of communication with postage or cost of transmission provided for and properly addressed and, in the case of an instrument to an address specified thereon or otherwise agreed, or if no address is specified, to any address reasonable under the circumstances. The foregoing method of delivery includes delivery by any commercial carrier that requests and maintains a receipt for delivery of written documents and also includes an electronic record as set forth in the Uniform Electronic Transactions Act if the sender and recipient have previously communicated by electronic means. In the event any writing is transmitted by mail with the United States postal service, such writing shall be mailed by first class mail, by certified mail, return receipt requested, or by mail delivery requiring a receipt for delivery. The time a writing is deemed to have been sent is the time at which the writing is deposited in the mail or delivered for transmission by any other means and, in the case of an electronic record, the time of sending is as specified in W.S. 40-21-115 ;
    13. “Written” or “writing” means printing, typewriting or any other intentional reduction to tangible form, including an electronic record created, generated, sent, communicated, received or restored by electronic means;
    14. “This act” means W.S. 29-1-103 through 29-10-106 .
  2. Only the following agency relationships are presumed in this act:
    1. If any spouse enters into a contract for the performance of any work or the furnishing of any materials for the benefit of the property of the other spouse for which a lien is provided by this act, the spouse contracting for the work shall be presumed to be the agent of the spouse owning the property;
    2. Between joint tenants;
    3. Among tenants in common; and
    4. An employee is an agent of his employer.

History. Laws 1981, Sp. Sess., ch. 17, § 1; 2010, ch. 92, § 2; 2011, ch. 130, § 1; 2012, ch. 35, § 1.

The 2010 amendment, effective July 1, 2011, substituted “act” for “title” in the introductory language of (a) and (b) and in (a)(iv) and (b)(i); deleted “as used in this act” following “ ‘Owner’ ” in the introductory language of (a)(v); in (a)(vi), deleted “or ‘materialman’ ” preceding “means a person,” substituted “for” for “or furnishing materials to an owner or” and inserted “or subcontractor”; and added (a)(viii) through (a)(xiv).

The 2011 amendment, effective July 1, 2011, in (a)(xii), inserted “first class mail, by.”

The 2012 amendment, effective July 1, 2012, added (a)(viii)(C) and made related changes.

Editor's notes. —

There is no subparagraph (a)(i)(B) in this section as it appears in the printed acts.

Laws 2012, ch. 35, § 2, effective July 1, 2012, provides: “This act shall apply to all fuel or lubricants furnished to a construction project on or after July 1, 2012.”

Company furnishing materials for construction, but not installing materials, deemed “materialman,” not “contractor.” —

A company who entered a contract with the record owner of real property to furnish materials for the construction of a home on the property, but installed no materials into the new home, was a “materialman,” not a “contractor,” and had to file its lien statement within the 90-day time period provided by § 29-2-106(a). Weyerhaeuser Co. v. Walters, 707 P.2d 733, 1985 Wyo. LEXIS 585 (Wyo. 1985).

Notice of intention to file lien sent to present owners of property. —

Inasmuch as the lien claimant failed to comply with the statutory requirement of giving proper notice to the owners of the property at the time the notice of intention to file lien was sent, although these parties were not the record owners at the time the claimant entered into a contract to supply materials to the then record owner, the lien was ineffective. Weyerhaeuser Co. v. Walters, 707 P.2d 733, 1985 Wyo. LEXIS 585 (Wyo. 1985).

Subsection (b) does not abrogate general law of agency for purposes of making lien statements. Stricker v. Frauendienst, 669 P.2d 520, 1983 Wyo. LEXIS 363 (Wyo. 1983).

Applied in

D & L Bldg., Inc. v. State ex rel. Maltby Tank & Barge, Inc., 747 P.2d 517, 1987 Wyo. LEXIS 564 (Wyo. 1987).

Cited in

Diamond Hill Inv. Co. v. Shelden, 767 P.2d 1005, 1989 Wyo. LEXIS 15 (Wyo. 1989).

Am. Jur. 2d, ALR and C.J.S. references. —

Vacation and sick pay and other fringe benefits as within mechanic's lien statute, 20 ALR4th 1268.

Article 3. Practice and Procedure

Am. Jur. 2d, ALR and C.J.S. references. —

56 C.J.S. Mechanics' Liens § 270.

§ 29-1-301. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1877, p. 78, § 6, related to Lien statement to be filed; contents; notice; fee.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-302. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1877, p. 80, § 16, related to notice of satisfaction to be filed.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

Cited in

Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980); Zitterkopf v. Bradbury, 783 P.2d 1142, 1989 Wyo. LEXIS 235 (Wyo. 1989).

§ 29-1-303. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from C.L. 1876, ch. 81, § 17, related to liability for failure to enter satisfaction.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

Cited in

Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980).

§ 29-1-304. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1981, Sp. Sess., ch. 17, § 1, related to Rules of Civil Procedure applicable in foreclosure action.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-305. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1981, Sp. Sess., ch. 17, § 1, related to priority of liens.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-306. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1981, Sp. Sess., ch. 17, § 1, related to work or materials furnished considered done under same contract; exceptions.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-307. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1981, Sp. Sess., ch. 17, § 1, related to notice of foreclosure to prior perfected lienholders, and effect of failure to notify.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-308. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1981, Sp. Sess., ch. 17, § 1, related to remedies not exclusive.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-309. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1981, Sp. Sess., ch. 17, § 1, related filing and recording fees.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-310. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1983, ch. 130, § 1, related to bond to satisfy lien; terms of bond; filing and effect thereof; and action upon bond.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-311. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1997, ch. 127, § 1, related to false or frivolous liens; damages; penalties.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

§ 29-1-312. Lien statement to be filed; contents; notice; fee.

  1. In order to have a perfected lien pursuant to this act, a lien claimant shall file with the county clerk a lien statement verifying the accuracy of the lien and the allegations set forth in the lien statement, sworn to and acknowledged by the lien claimant or his authorized representative before a notarial officer. The county clerk shall record and index the lien statement by date, names of claimant and property owner, and legal description of the property.
  2. The lien statement shall contain as appropriate the following information:
    1. The name and address of the lien claimant;
    2. The amount claimed to be due and owing;
    3. The name and address of the record owner against whose property the lien is filed;
    4. An itemized list setting forth and describing materials delivered or work performed;
    5. The name of the person whom the lien claimant alleges is contractually responsible to pay the debt secured by the lien;
    6. The date when labor was last performed or services were last rendered or the date of substantial completion of the project;
    7. The legal description of the property where the materials were furnished or upon which the work was performed; and
    8. A copy of the contract, if available, or a summary of the lien claimant’s contract together with a statement of the location where a copy of the contract, if written, can be obtained.
  3. Notice shall be sent by the lien claimant to the last record owner or his agent in the case of a real property lien within thirty (30) days after the lien statement is filed. The notice shall be in substantially the same format and contain the same information as the form of notice specified in W.S. 29-10-103 . The notice forms shall be made available and may be obtained at the county clerk’s office of each county. Failure to send the notice required under this subsection shall not affect the validity of the lien.
  4. As a fee for recording a lien statement, the county clerk shall collect from the lien claimant the same fee as provided by W.S. 18-3-402(a)(xvi)(P). An irregularity in the lien statement may provide a valid defense for a party defending against the lien. The county clerk shall nevertheless file a lien statement at the date and time received by the county clerk, regardless of any irregularity, illegible language or other reason.
  5. The recording fee under this section may be assessed as costs in any action to foreclose the lien.
  6. The lien statement shall be in substantially the same format and contain the same information as the form specified in W.S. 29-10-104 . The lien statement forms shall be made available and may be obtained at the county clerk’s office of each county.

History. Laws 2010, ch. 92, § 1; 2013, ch. 122, § 1.

The 2013 amendment, effective July 1, 2013, substituted “thirty (30)” for “five (5)”, and added the last sentence in (c).

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

Application. —

Former statute that required prompt lien notice applies to projects under construction prior to the effective date of the statute requiring 5 days' notice; therefore, a lien was improperly invalidated because prompt notice was given where a week passed that included a weekend and a legal holiday. An argument that a printed version did not contain a session law relating to the effectiveness of the new statute was rejected because enrolled bills governed over incorrect or incomplete printed versions. Elec. Wholesale Supply Co. v. Fraser, 2015 WY 105, 356 P.3d 254, 2015 Wyo. LEXIS 121 (Wyo. 2015).

Improper filing of attorney's lien. —

Attorney violated professional conduct rules and was suspended for 30 days for misrepresentations in filing a lien statement where the lien was filed under a statute that applied to improvements to real property, and no notice was provided. Moreover, the attorney failed to make any limitation to exclude the assets of a spouse, and she attached an inaccurate and unreasonable billing statement to the sworn lien statement that was filed with a county clerk. Bd. of Prof'l Responsibility v. Casper, 2014 WY 22, 318 P.3d 790, 2014 Wyo. LEXIS 27 (Wyo. 2014).

Remedy unavailable unless services received by landowner. —

Where a landowner never actually received anything in the way of permits, fees, connections or service from a water district for which he did not pay, a mechanics' lien is a remedy that the district did not have available. Thus, the court should have dismissed the complaint for failure to assert the statutory mechanics' lien requirements necessary to vest jurisdiction in the court. Robbins v. South Cheyenne Water & Sewage Dist., 792 P.2d 1380, 1990 Wyo. LEXIS 64 (Wyo. 1990).

Lien statement may be made and signed by attorney of claimant. Stricker v. Frauendienst, 669 P.2d 520, 1983 Wyo. LEXIS 363 (Wyo. 1983).

Description of premises sufficient unless prejudicial. —

Absent any such claim of prejudice or being misled in any manner by the description which appears in the lien statement, the court must hold that it is sufficient. Horseshoe Estates v. 2M Co., 713 P.2d 776 (Wyo. 1986).

§ 29-1-313. Notice of satisfaction to be filed.

  1. Whenever any debt which is secured by a lien pursuant to this act is paid and satisfied, the lien claimant shall file notice of satisfaction of the lien in the office of the county clerk of any county in which the lien is filed and the lien claimant shall send the record owner a copy of the notice of satisfaction within thirty (30) days. The county clerk shall record and index the notice of satisfaction of the lien. The notice of satisfaction shall be acknowledged, but may be signed by the lien claimant or the attorney for the lien claimant.
  2. The notice of satisfaction shall be in substantially the same format and contain the same information as the notice of satisfaction form in W.S. 29-10-106 . The notice of satisfaction forms shall be made available and may be obtained at the county clerk’s office of each county.

History. Laws 2010, ch. 92, § 1; 2013, ch. 122, § 1.

The 2013 amendment, effective July 1, 2013, substituted “thirty (30)” for “five (5)” in (a).

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

§ 29-1-314. Liability for failure to file a notice of satisfaction.

In addition to any actual damages, any lien claimant refusing or neglecting to file the notice of satisfaction as provided in W.S. 29-1-313 within thirty (30) days after payment, and after having received by certified or registered mail a request in writing to file the notice of satisfaction, is liable for damages of not less than one-tenth of one percent (.10%) of the original principal amount of the debt per day from the date the lien claimant receives the written request to file a notice of satisfaction, until the lien claimant files a notice of satisfaction. The damages authorized by this section shall not exceed one hundred dollars ($100.00) per day.

History. Laws 2010, ch. 92, § 1.

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

Article 4. Actions To Foreclose Liens

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

§ 29-1-401. Jurisdiction of circuit and district court; Rules of Civil Procedure applicable in foreclosure action; attorney fees.

  1. All actions to foreclose a lien perfected under this act are quasi in rem proceedings and shall be commenced by filing a complaint in either the district court or, when required under W.S. 5-9-128(a)(vi), in the circuit court, in any county in which the property subject to the lien is located.
  2. In any action to foreclose a lien the Wyoming Rules of Civil Procedure shall govern.
  3. In the event an action is filed to foreclose a lien pursuant to this act, the prevailing party shall be entitled to recover from the nonprevailing party all costs and expenses reasonably associated with the action, including but not limited to reasonable attorney fees.
  4. Nothing in this section shall be construed to require a lien claimant to enforce his lien under this article if another method of enforcement is available under this act.

History. Laws 2010, ch. 92, § 1.

§ 29-1-402. Priority of liens.

  1. Except as provided in this section, the liens provided by this act shall be on an equal footing without reference to the date of the filing of the lien statement.
  2. Any lien perfected in compliance with this act attaches to the real property, fixtures, materials, machinery or supplies furnished and improvements made in preference to any subsequent lien, security interest or mortgage under any other provision of law which has been perfected upon real or personal property, including a leasehold interest, against which the lien is claimed.
  3. Any lien, security interest or mortgage which has been perfected upon real or personal property or upon a leasehold interest prior to the commencement of any construction work or repair of the premises or property, except as provided by chapter 7 of this act, or W.S. 29-8-102 relating to liens for the production of farm products under contracts executed, entered into, renewed or substantively amended on or after July 1, 2001, shall have priority.
  4. Where a sale is ordered by the court on foreclosure of any lien provided by this act and the proceeds from the sale are insufficient to discharge in full all of the liens, the proceeds shall be prorated among the several lien claimants according to the amounts of their respective claims.

History. Laws 2010, ch. 92, § 1.

Editor's notes. —

The repealed section, which derived from Laws 1981, Sp. Sess., ch. 17, § 1, related to priority of liens.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

Priority of subcontractor's lien relates back to commencement of construction on project. —

Cessation of construction does not preclude such a relation back. Thatcher & Sons v. Norwest Bank Casper, 750 P.2d 1324, 1988 Wyo. LEXIS 62 (Wyo. 1988).

Cited in

Bowles v. Sunrise Home Ctr., Inc., 847 P.2d 1002, 1993 Wyo. LEXIS 39 (Wyo. 1993); Keith L. Dobson & Aspen Constr. Co. v. Portrait Homes, Inc., 2005 WY 95, 117 P.3d 1200, 2005 Wyo. LEXIS 114 (2005).

Am. Jur. 2d, ALR and C.J.S. references. —

Attorney's charging lien as including services rendered or disbursements made in other than instant action or proceeding, 23 ALR4th 336.

Priority between attorney's lien for fees against a judgment and lien of creditor against same judgment, 34 ALR4th 665.

Priority between attorney's charging lien against judgment and opposing party's right of setoff against same judgment, 27 ALR5th 764.

§ 29-1-403. Work or materials furnished considered done under same contract; exceptions.

All work performed or materials furnished by a lien claimant shall be considered as having been done under the same contract unless more than one hundred eighty (180) days elapse from the date of the performance of any work or the furnishing of any materials and the date when work or materials are next performed or furnished by the lien claimant.

History. Laws 2010, ch. 92, § 1.

§ 29-1-404. Notice of foreclosure to prior perfected lienholders; effect of failure to notify.

The holder of any prior perfected lien upon the real property is entitled to notice in suits to foreclose the lien. A foreclosure proceeding shall not be rendered invalid by failure to give the notice required by this section.

History. Laws 2010, ch. 92, § 1.

§ 29-1-405. Remedies not exclusive.

The remedies provided by this act are not exclusive.

History. Laws 2010, ch. 92, § 1.

§ 29-1-406. Filing and recording fees.

The county clerk shall be paid the same fees as provided by W.S. 18-3-402 for recording all papers under this act.

History. Laws 2010, ch. 92, § 1.

§ 29-1-407. Consent to jurisdiction and venue.

By contracting to perform work or furnish materials on a project located in Wyoming, each contractor, subcontractor and materialman who asserts a lien submits to the laws of Wyoming and the jurisdiction of the district and circuit courts in the county in which the project is situated with respect to all lien claims, regardless of whether the lien claimant is a resident of Wyoming and regardless of whether the contract contains a contrary choice of law or venue provision. Venue for any mediation or arbitration of lien claims shall be proper only in the county in which the project is located, unless the parties agree otherwise.

History. Laws 2010, ch. 92, § 1.

Article 5. Substitute Security for Liens

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

§ 29-1-501. Substitute security to satisfy lien; filing and effect thereof; action upon security.

  1. Any lien created pursuant to this act filed against any real or personal property is satisfied if the owner of the property, contractor or subcontractor has deposited with the court having jurisdiction over the lien claim a corporate surety bond, letter of credit, cash or cash equivalent of established value approved by the court having jurisdiction over the lien claim in the county where the lien was filed in an amount equal to one and one-half (11/2) times the amount of the lien.
  2. The security shall guarantee that if the lien claimant is finally adjudged to be entitled to recover upon the lien, the principal or his sureties, jointly and severally, in the case of a bond, or the issuer of a letter of credit shall pay the lien claimant the amount of the judgment for at least the amount for which the lien was filed plus costs and attorneys’ fees.
  3. The security may be deposited any time prior to entry of a final judgment in an action to foreclose the lien.
  4. The security shall be deposited with the clerk of the court having jurisdiction over the lien claim in the county where the lien was filed.
  5. Upon depositing the security and entry of an order of the court accepting the security, the lien against the property shall be forthwith discharged and released in full, and the security deposited pursuant to this section shall be substituted. The clerk of court shall issue a notice of satisfaction of lien which the owner or lien claimant may file in the office of the county clerk where the lien was filed which shall show that the lien has been satisfied.
  6. A lien claimant whose lien has been satisfied by the substitution of the security pursuant to subsection (e) of this section may bring an action upon the security. The action shall be commenced in the court in which the security was deposited under subsection (d) of this section.

History. Laws 2010, ch. 92, § 1.

Article 6. False or Frivolous Liens

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

§ 29-1-601. False or frivolous liens; damages; penalties.

  1. Any claim of lien against a federal, state or local official or employee based on the performance or nonperformance of that official’s or employee’s duties shall be invalid unless accompanied by a specific order from a court of competent jurisdiction authorizing the filing of the lien or unless a specific statute authorizes the filing of the lien. A federal, state or local official or employee may discharge a lien under subsection (b) or (d) of this section.
  2. Any person whose real or personal property is subject to a recorded claim of lien who believes the claim of lien is invalid under subsection (a) of this section, was forged, or that the lien claimant knew at the time of filing that the lien was groundless, contained a material misstatement or false claim, may petition the court having jurisdiction over the lien of the county in which the claim of lien has been recorded for the relief provided in this subsection. The petition shall state the grounds upon which relief is requested, and shall be supported by the affidavit of the petitioner or his attorney setting forth a concise statement of the facts upon which the motion is based. The clerk of court shall assign a case number to the petition and obtain from the petitioner a filing fee of thirty-five dollars ($35.00). Upon the filing of the petition the following shall apply:
    1. The court may enter its order, which may be granted ex parte, directing the lien claimant to appear before the court at a time no earlier than six (6) nor later than fifteen (15) days following the date of service of the petition, and order the lien claimant to show cause, if any, why the relief provided in this subsection should not be granted;
    2. The order shall clearly state that if the lien claimant fails to appear at the time and place noted, the claim of lien shall be stricken and released, and that the lien claimant shall be ordered to pay damages of at least one thousand dollars ($1,000.00) or actual damages, whichever is greater, and the costs incurred by the petitioner, including reasonable attorneys’ fees;
    3. The order and petition shall be served upon the lien claimant by personal service, or, where the court determines that service by mail or other comparable method of delivery is likely to give actual notice, the court may order that service be made by mailing or delivering copies of the petition and order to the lien claimant at his last known address or any other address determined by the court to be appropriate. Two (2) copies shall be sent, one (1) by ordinary first class mail and the other by a form of mail or other delivery method requiring a signed receipt showing when and to whom it was delivered. The envelopes shall bear the return address of the sender;
    4. If, following a hearing on the matter the court determines that the claim of lien is invalid under subsection (a) of this section, was forged or that the lien claimant knew at the time of filing that the lien was groundless or contained a material misstatement or false claim, the court shall issue an order striking and releasing the claim of lien and awarding damages of one thousand dollars ($1,000.00) or actual damages, whichever is greater, costs and reasonable attorneys’ fees to the petitioner to be paid by the lien claimant;
    5. If the court determines that the claim of lien is valid, the court shall issue an order so stating and shall award costs and reasonable attorneys’ fees to the lien claimant to be paid by the petitioner.
  3. Any person who offers to have recorded or filed a forged or groundless lien in violation of this section with the intent to threaten, harass or intimidate a public official or employee in the performance or nonperformance of his official duties is guilty of a misdemeanor punishable by a fine of not more than seven hundred fifty dollars ($750.00), imprisonment for not more than six (6) months, or both.
  4. Any federal, state or local official or employee whose real or personal property is subject to a recorded claim of lien who believes the claim of lien is invalid under subsection (a) of this section may record an affidavit as affiant with the county clerk stating that the claim of lien has been filed against him in his individual capacity for the performance or nonperformance of actions in his capacity as a government official or employee. The person alleging the claim of lien was filed in violation of subsection (a) of this section shall provide notice of the filing of the affidavit to the lien claimant at the address provided on the lien statement pursuant to W.S. 29-1-312(b) by first class mail. Upon the filing of the affidavit, the lien claimant shall have twenty (20) days to file a petition in the district court for the county in which the lien statement was filed stating that the claim of lien is valid under the laws of the United States or of the state of Wyoming. If the lien claimant fails to file the petition within the time specified, the affiant may present a copy of the affidavit to the district court clerk for the county in which the lien statement was filed showing the date it was recorded and the district court clerk shall issue a certification that no petition has been filed in response to the affidavit. Upon recording of a certification issued under this subsection with the county clerk, the lien shall be null and void and of no further force or effect. Upon the filing of the petition by the lien claimant the following shall apply:
    1. The court may enter its order directing the lien claimant to appear before the court at a time no earlier than six (6) nor later than fifteen (15) days following the date of service of the petition, and order the lien claimant to show cause, if any, why the relief provided in this subsection should not be granted;
    2. The order shall clearly state that if the lien claimant fails to appear at the time and place noted, the claim of lien shall be stricken and released, and that the lien claimant shall be ordered to pay damages of one thousand dollars ($1,000.00) or actual damages, whichever is greater, and the costs incurred by the petitioner, including reasonable attorneys’ fees;
    3. If, following a hearing on the matter the court determines that the claim of lien is invalid under subsection (a) of this section the court shall issue an order striking and releasing the claim of lien and awarding damages of one thousand dollars ($1,000.00) or actual damages, whichever is greater, costs and reasonable attorneys’ fees to the petitioner to be paid by the lien claimant;
    4. If the court determines that the claim of lien is valid, the court shall issue an order so stating and shall award costs and reasonable attorneys’ fees to the lien claimant to be paid by the affiant.

History. Laws 2010, ch. 92, § 1; 2013, ch. 53, § 1.

The 2013 amendment, effective March 15, 2013, added the last sentence in (a); and added (d).

Applicability. —

Laws 2013, ch. 53, § 3, directs: “This act shall apply to all liens filed on or after March 15, 2013.”

Medicaid lien. —

When the Department of Health asserted a lien against a house owned by a deceased Medicaid recipient and the recipient's spouse as tenants by the entirety, upon the spouse's death, the spouse's estate was not entitled to relief for the filing of a false lien because the lien was valid. Estate of Marusich v. State ex rel. Dep't of Health, 2013 WY 150, 313 P.3d 1272, 2013 Wyo. LEXIS 158 (Wyo. 2013).

Quoted in

Gheen v. State ex rel. Dep't of Health, 2014 WY 70, 2014 Wyo. LEXIS 75 (May 30, 2014).

Chapter 2 Contractors or Materialmen

In interpretation of lien laws, supreme court has considered decisions of Missouri, the jurisdiction of the law or origin, to be persuasive. Arch Sellery, Inc. v. Simpson, 346 P.2d 1068, 1959 Wyo. LEXIS 48 (Wyo. 1959); True v. Hi-Plains Elevator Mach., 577 P.2d 991, 1978 Wyo. LEXIS 281 (Wyo. 1978).

Mechanics' liens laws are intended to create means of securing claims of a particular class of creditors and to prevent unjust enrichment arising out of the enhancement of value of property from labor and materials which would otherwise go without payment. Engle v. First Nat'l Bank, 590 P.2d 826, 1979 Wyo. LEXIS 362 (Wyo. 1979).

Applied in

Elder v. Jones, 608 P.2d 654, 1980 Wyo. LEXIS 246 (Wyo. 1980).

Am. Jur. 2d, ALR and C.J.S. references. —

53 Am. Jur. 2d Mechanics' Liens § 1 et seq.

Priority as between lien for repairs and right of seller under conditional contract, 36 ALR2d 198.

Statutes as to actions by person doing business under an assumed or fictitious name or designation not showing names of persons interested as applicable to filing of lien for repairs, 42 ALR2d 516.

Amount for which mechanic's lien may be obtained where contract has been terminated or abandoned by consent of parties or without fault on contractor's part, 51 ALR2d 1009.

Validity of statute making private property owner liable to contractor's laborers, materialmen or subcontractors where owner fails to exact bond or employ other means of securing their payment, 59 ALR2d 885.

Taking or negotiation of unsecured note of owner or contractor as waiver of lien, 91 ALR2d 425.

Mechanic's lien based on contract with vendor pending executory contract for sale of property as affecting purchaser's interest, 50 ALR3d 944.

Amount of compensation for attorney's services in absence of contract or statute fixing amount, 57 ALR3d 475, 58 ALR3d 201, 59 ALR3d 152.

Effect of bankruptcy of principal contractor upon mechanic's lien of a subcontractor, laborer or materialman as against owner of property, 69 ALR3d 1342.

Demand for or submission to arbitration as affecting enforcement of mechanic's lien, 73 ALR3d 1042.

Filing of mechanic's lien or proceeding for its enforcement as affecting right to arbitration, 73 ALR3d 1066.

Who is the “owner” within the mechanic's lien statute requiring notice of claim, 76 ALR3d 605.

Right of vendee under executory land contract to lien for amount paid on purchase price as against subsequent creditors of purchasers from vendor, 82 ALR3d 1040.

Right of subcontractor's subcontractor or materialman, or of materialman's materialman, to mechanic's lien, 24 ALR4th 963.

Landlord's liability to third party for repairs authorized by tenant, 46 ALR5th 1.

§ 29-2-101. Persons entitled to liens; extent of lien on realty; exceptions.

  1. Every contractor, subcontractor or materialman performing any work on or furnishing any materials for any building or any improvement upon real property shall have for his work done or plans or materials furnished a lien upon the building or improvements, and upon the real property of the owner on which they are situated to the extent of one (1) acre. If the improvements cover more than one (1) acre the lien shall extend to all the additional real property covered thereby.
  2. To have a lien the work or materials shall be furnished under a contract.
  3. Notwithstanding subsection (a) of this section if the real property subject to a lien is located in any city, town or subdivision the lien shall extend to the entire lot upon which the building or improvement is located.
  4. A cooperative utility, as defined by W.S. 17-20-140(a)(i), shall have a lien for the materials or services provided to a member. The lien shall attach to the real property of the member at the location where the materials or services were provided, if the amount due to the utility:
    1. Is greater than five thousand dollars ($5,000.00); and
    2. Has been unpaid for more than ninety (90) days.
  5. The lien under this section shall extend to the owner’s real property and easements to the extent necessary to provide legal access by a roadway for ingress and egress to the building, improvements or real property subject to the lien, not to exceed forty (40) feet in width to the nearest easement, public road or highway.

History. Laws 1877, p. 77, § 1; R.S. 1887, § 1517; R.S. 1899, § 2889; C.S. 1910, § 3799; C.S. 1920, § 4859; R.S. 1931, § 66-501; C.S. 1945, § 55-201; W.S. 1957, § 29-4; W.S. 1977, § 29-2-102 ; Laws 1981, Sp. Sess., ch. 17, § 2; 1989, ch. 82, § 2; 2007, ch. 193, § 1; 2010, ch. 92, § 2.

The 2007 amendment, effective July 1, 2007, added subsection (d).

The 2010 amendment, effective July 1, 2011, in (a), deleted “Except as provided in W.S. 29-2-111” at the beginning, substituted “contractor, subcontractor or materialman” for “person,” deleted “or plans” following “furnishing any materials” and substituted “real property” for “land” throughout; substituted “real property” for “land” in (c); and added (e).

Constitutionality. —

Statute giving a subcontractor lien for labor and materials actually entering into the structure, as against an owner with whom he had no direct contractual relation, is constitutional. Becker v. Hopper, 22 Wyo. 237, 138 P. 179, 1914 Wyo. LEXIS 6 (Wyo. 1914).

Lien valid. —

Former statute that required prompt lien notice applies to projects under construction prior to the effective date of the statute requiring 5 days' notice; therefore, a lien was improperly invalidated because prompt notice was given where a week passed that included a weekend and a legal holiday. An argument that a printed version did not contain a session law relating to the effectiveness of the new statute was rejected because enrolled bills governed over incorrect or incomplete printed versions. Elec. Wholesale Supply Co. v. Fraser, 2015 WY 105, 356 P.3d 254, 2015 Wyo. LEXIS 121 (Wyo. 2015).

Full statutory compliances required for lien. —

Mechanics' liens were not recognized at and are in derogation of common law so there must be full compliance with legislative requirements, as statutory lien laws must be strictly construed and their scope cannot be extended. American Bldgs. Co. v. Wheelers Stores, 585 P.2d 845, 1978 Wyo. LEXIS 239 (Wyo. 1978).

“Contractor.” —

When a contract concerns the construction of improvements to real property, “contractor” has a specialized meaning related to the building trades; and it is in this sense that “contractor” is connected to the law of mechanics' liens. American Bldgs. Co. v. Wheelers Stores, 585 P.2d 845, 1978 Wyo. LEXIS 239 (Wyo. 1978).

“Subcontractor.” —

In building contracts, a “subcontractor” is one who assumes performance of a portion or all of the contract work which the contractor has obligated himself to perform under contract with the owner. American Bldgs. Co. v. Wheelers Stores, 585 P.2d 845, 1978 Wyo. LEXIS 239 (Wyo. 1978).

“Materialman.” —

One who merely furnishes materials to the owner or a contractor is a materialman, and not a contractor or subcontractor, within the meaning of the mechanics' lien laws. American Bldgs. Co. v. Wheelers Stores, 585 P.2d 845, 1978 Wyo. LEXIS 239 (Wyo. 1978).

One who not only furnishes materials, but installs them, is a contractor or a subcontractor, and not a materialman, within the meaning of mechanics' lien laws. American Bldgs. Co. v. Wheelers Stores, 585 P.2d 845, 1978 Wyo. LEXIS 239 (Wyo. 1978).

Delivery of materials sustains lien. —

Provided the other requirements of this section are met, a delivery of materials to the building site is sufficient to sustain a mechanic's lien, even though the material, without the materialman's fault or consent, is never used or is diverted to some other use. Schaefer v. Lampert Lumber Co., 591 P.2d 1225, 1979 Wyo. LEXIS 382 (Wyo. 1979).

Forfeiture under this section is not favored unless there is some specific provision made for it. Engle v. First Nat'l Bank, 590 P.2d 826, 1979 Wyo. LEXIS 362 (Wyo. 1979).

Inclusion in description of more land than lien may attach does not vitiate lien upon so much of the land as the lien may attach. Engle v. First Nat'l Bank, 590 P.2d 826, 1979 Wyo. LEXIS 362 (Wyo. 1979).

Contract authorizing filing of lien may be either express or implied. —

In order to authorize the filing of a lien under this section the existence of a contract is necessary, but it may be either express or implied. Arch Sellery, Inc. v. Simpson, 346 P.2d 1068, 1959 Wyo. LEXIS 48 (Wyo. 1959).

An implied contract is amply sufficient upon which to base a mechanic's lien. Jordan v. Natrona Lumber Co., 52 Wyo. 393, 75 P.2d 378, 1938 Wyo. LEXIS 34 (Wyo. 1938).

This section does not call for a written contract or express contract or formal contract; an implied contract is sufficient upon which to base a mechanic's lien. Engle v. First Nat'l Bank, 590 P.2d 826, 1979 Wyo. LEXIS 362 (Wyo. 1979).

Although a contractor approved a subcontractor's invoices in excess of the target price without increasing the amount in writing as specified in the contract, the labor and materials were furnished under a contract and did not exceed the contract price because the claimed lien amount had been approved under the contract by the conduct of the parties. KM Upstream, LLC v. Elkhorn Constr., Inc., 2012 WY 79, 278 P.3d 711, 2012 Wyo. LEXIS 84 (Wyo. 2012).

Performance may give rise to contract. —

Under this section, acceptance of or acquiescence in a performance will give rise to a valid contract. Schaefer v. Lampert Lumber Co., 591 P.2d 1225, 1979 Wyo. LEXIS 382 (Wyo. 1979).

Conduct showing ratification of contract. —

Where husband and wife decided to build a home on a lot jointly owned by them, wife selected plans and specifications, went with husband to architect to have the plans drawn, joined in mortgage to obtain money for construction, and was often upon premises as work progressed, her conduct showed that she either authorized or ratified husband's act in contracting for construction of the house. Phelan v. Cheyenne Brick Co., 26 Wyo. 493, 188 P. 354, 1920 Wyo. LEXIS 10 (Wyo.), reh'g denied, 26 Wyo. 493, 189 P. 1103, 1920 Wyo. LEXIS 11 (Wyo. 1920).

Where wife not made party. —

Subcontractor was not entitled to foreclose mechanic's lien against property held by husband and wife by entirety by virtue of deed recorded 2 months after filing of lien statement in which wife was not named where wife was not made party to suit to foreclose until 3 years after filing lien statement. Peters v. Dona, 49 Wyo. 306, 54 P.2d 817, 1936 Wyo. LEXIS 45 (Wyo. 1936).

Owner of equitable title cannot burden legal title with liens. Sargent v. Delgado, 492 P.2d 193, 1972 Wyo. LEXIS 212 (Wyo. 1972).

Thus contract made by vendee for labor and materials will not subject legal owner's interest to a lien, even if the latter has knowledge that the labor and materials are being furnished. Sargent v. Delgado, 492 P.2d 193, 1972 Wyo. LEXIS 212 (Wyo. 1972).

Materialman supplying materialman not afforded lien. —

A materialman supplying a materialman is too remote a relationship to be within the sphere of statutory protection affording a lien to suppliers of materials. American Bldgs. Co. v. Wheelers Stores, 585 P.2d 845, 1978 Wyo. LEXIS 239 (Wyo. 1978).

Superintendent's lien for services. —

Superintendent and engineer in charge of construction of plant who also performed work was entitled to lien for his salary. Continental & Commercial Trust & Sav. Bank v. North Platte Valley Irr. Co., 219 F. 438, 1915 U.S. App. LEXIS 1639 (8th Cir. Wyo. 1915).

Lien on leased premises. —

Under lease by which lessor obligates lessee as part consideration to make permanent and substantial improvements on a building, and lessee fails to pay materialman for materials furnished, latter has right to claim a lien upon the lease premises, lessee being presumed to be lessor's agent. Jordan v. Natrona Lumber Co., 52 Wyo. 393, 75 P.2d 378, 1938 Wyo. LEXIS 34 (Wyo. 1938).

Subcontractor's lien does not depend on condition of accounts between owner and contractor and is not defeated because nothing is due from owner to contractor. Becker v. Hopper, 23 Wyo. 209, 147 P. 1085, 1914 Wyo. LEXIS 32 (Wyo. 1914).

Sufficiency of lien statement. —

Under this section, giving mechanic's lien upon compliance with provisions of this chapter, and § 29-2-109 , prescribing lien statement to be filed, a lien statement, “Becker Hotel contract, tin work, etc., $1,292,” was insufficient. Becker v. Hopper, 22 Wyo. 237, 138 P. 179, 1914 Wyo. LEXIS 6 (Wyo. 1914).

Although a subcontractor's lien statement did not specifically reference this section, it adequately set forth both a mechanic's lien claim and an oil and gas lien claim. KM Upstream, LLC v. Elkhorn Constr., Inc., 2012 WY 79, 278 P.3d 711, 2012 Wyo. LEXIS 84 (Wyo. 2012).

No lien on school building. —

The statute giving liens for materials used in constructing buildings does not give lien on a county high school building for brick furnished and used in the construction thereof. Peters v. Killibrew, 24 Wyo. 53, 154 P. 996, 1916 Wyo. LEXIS 9 (Wyo. 1916).

Dwelling house erected upon land held in trust by United States for benefit of its Indian ward, under contract with the Indian, is not subject to the state law of Wyoming providing for mechanics' liens, and such dwelling house may not be sold to satisfy such liens. United States v. Chinburg, 224 F.2d 177, 1955 U.S. App. LEXIS 4059 (10th Cir. Wyo.), cert. denied, 350 U.S. 897, 76 S. Ct. 156, 100 L. Ed. 788, 1955 U.S. LEXIS 163 (U.S. 1955).

Lien allowable on where building located. —

Where building was located on lots 5 and 6, but court permitted foreclosure against lots 5, 6 and 7, decree should be modified by excluding lot 7, since lien is allowable only on lots on which building is located. Mawson-Peterson Lumber Co. v. Sprinkle, 59 Wyo. 334, 140 P.2d 588, 1943 Wyo. LEXIS 18 (Wyo. 1943).

Applied in

Lasich v. Wimpenney, 73 Wyo. 345, 278 P.2d 807, 1955 Wyo. LEXIS 3 (1955).

Quoted in

Minnehoma Fin. Co. v. Pauli, 565 P.2d 835, 1977 Wyo. LEXIS 308 (Wyo. 1977); Weyerhaeuser Co. v. Walters, 707 P.2d 733, 1985 Wyo. LEXIS 585 (Wyo. 1985).

Cited in

Davis v. Big Horn Lumber Co., 14 Wyo. 517, 85 P. 980, 1906 Wyo. LEXIS 29 (1906); United Pac. Ins. Co. v. Martin & Luther Gen. Contractors, 455 P.2d 664, 1969 Wyo. LEXIS 142 (Wyo. 1969); True v. Hi-Plains Elevator Mach., Inc., 577 P.2d 991, 1978 Wyo. LEXIS 281 (Wyo. 1978); Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980); Keith L. Dobson & Aspen Constr. Co. v. Portrait Homes, Inc., 2005 WY 95, 117 P.3d 1200, 2005 Wyo. LEXIS 114 (2005).

Law reviews. —

See note, “Wilful Abandonment and Enforcement of a Mechanic's Lien,” 5 Wyo. L.J. 205.

For case note, “Who is a Contractor under Mechanics' Lien Law. American Bldgs. Co. v. Wheelers Stores, 585 P.2d 845, 1978 Wyo. LEXIS 239 (Wyo. 1978),” see 14 Land & Water L. Rev. 635 (1979).

Am. Jur. 2d, ALR and C.J.S. references. —

Right to mechanic's lien for “labor” or “work,” in case of preparatory or fabricating work done on materials intended for use and used in particular building or structure, 25 ALR2d 1370.

Delivery of material to building site as sustaining mechanic's lien, 39 ALR2d 394.

Mechanic's lien for landscaping, 39 ALR2d 866.

Grading, clearing, filling, excavating and the like, 39 ALR2d 866.

Right to mechanic's lien upon leasehold for supplying labor or material in attaching or installing fixtures, 42 ALR2d 685.

Amount for which mechanic's lien may be obtained where contract has been terminated or abandoned by consent of parties or without fault on contractor's part, 51 ALR2d 1009.

Lien for improvements made or placed on premises of another by mistake, 57 ALR2d 263.

Validity of statute making private property owner liable to contractor's laborers, materialmen or subcontractors, where owner fails to exact bond or employ other means of securing their payment, 59 ALR2d 885.

Estate by entireties, interest in, as subject to mechanic's lien in satisfaction of his or her individual debt, 75 ALR2d 1172.

Contract against mechanic's lien, validity and effect, 76 ALR2d 1087.

Mortgages, priority, 80 ALR2d 179.

Subdividing land, services in connection with, 87 ALR2d 1004.

Water well-drilling contract, work under, 90 ALR2d 1346.

Rights and liabilities with respect to natural gas reduced to possession and subsequently stored in natural reservoir, 94 ALR2d 543.

Swimming pool as lienable item within mechanic's lien statute, 95 ALR2d 1371.

What constitutes commencement of building or improvement for purposes of determining accrual of lien, 1 ALR3d 822.

Charge for use of machinery, tools or appliances used in construction as basis for mechanic's lien, 3 ALR3d 573.

Single mechanic's lien under entire contract, against 2 or more separate buildings on different lots in same ownership, 15 ALR3d 73.

Surveyor's work as giving rise to right to mechanic's lien, 35 ALR3d 1391.

Mechanic's lien for labor or material furnished under contract with vendor pending executory contract for sale of property as affecting purchaser's interest, 50 ALR3d 944.

Municipal property as subject to mechanic's lien, 51 ALR3d 657.

Labor in examination, repair or servicing of fixtures, machinery or attachments in building, as supporting a mechanic's lien, or as extending time for filing such a lien, 51 ALR3d 1087.

Assertion of statutory mechanic's or materialman's lien against oil and gas produced or against proceeds attributable to oil and gas sold, 59 ALR3d 278.

Removal or demolition of building or other structure as basis for mechanic's lien, 74 ALR3d 386.

Release or waiver of mechanic's lien by general contractor as affecting rights of subcontractor or materialman, 75 ALR3d 505.

Vacation and sick pay and other fringe benefits as within mechanic's lien statute, 20 ALR4th 1268.

Right of subcontractor's subcontractor or materialman, or of materialman's materialman, to mechanic's lien, 24 ALR4th 963.

Delivery of material to building site as sustaining mechanic's lien — modern cases, 32 ALR4th 1130.

Architect's services as within mechanics' lien statute, 31 ALR5th 664.

Timeliness of notice to public works contractor on federal project, of indebtedness for labor or materials furnished, 69 ALR Fed 600.

§ 29-2-102. Extent of perfected lien.

Any lien properly perfected shall extend to the entire interest of the owner.

History. Laws 1877, p. 77, § 2; R.S. 1887, § 1518; R.S. 1899, § 2890; C.S. 1910, § 3800; C.S. 1920, § 4863; R.S. 1931, § 66-505; C.S. 1945, § 55-202; W.S. 1957, § 29-5; W.S. 1977, § 29-2-103 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Leased premises. —

Under lease by which lessor obligates lessee as part consideration to make permanent and substantial improvements on a building and lessee fails to pay materialman for materials furnished, latter has right to claim a lien upon the leased premises, lessee being presumed to be lessor's agent. Jordan v. Natrona Lumber Co., 52 Wyo. 393, 75 P.2d 378, 1938 Wyo. LEXIS 34 (Wyo. 1938).

Lien against estate. —

Where one, after erecting buildings on land of another, dies and his administratrix purchases the land and takes a deed thereof in her own name, using estate funds for that purpose, and rebuilds building after its destruction by fire, using insurance money belonging to the estate, a person who, without notice of rights of the estate, supplies labor and materials for the building, and files mechanic's lien therefor, acquires a lien on the building and land prior to rights of the heir. Seibel v. Bath, 5 Wyo. 409, 40 P. 756, 1895 Wyo. LEXIS 33 (Wyo. 1895).

Owner of equitable title cannot burden legal title with liens. Sargent v. Delgado, 492 P.2d 193, 1972 Wyo. LEXIS 212 (Wyo. 1972).

Thus contract made by vendee for labor and materials will not subject legal owner's interest to a lien, even if the latter has knowledge that the labor and materials are being furnished. Sargent v. Delgado, 492 P.2d 193, 1972 Wyo. LEXIS 212 (Wyo. 1972).

Cited in

Phelan v. Cheyenne Brick Co., 26 Wyo. 493, 188 P. 354, 1920 Wyo. LEXIS 10 (1920); Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980).

Am. Jur. 2d, ALR and C.J.S. references. —

Enforceability of single mechanic's lien upon several parcels against less than the entire property liened, 68 ALR3d 1300.

§ 29-2-103. Right of judicial sale and removal of improvements.

Any lien claimant enforcing the lien may have the building, improvements and real property sold under execution. However, if any party establishes that the real property, after removal of the improvement, would be in the same or similar condition as prior to the performance of the work for which the lien is claimed, the court may authorize the removal of the improvement. In addition to attorneys’ fees and costs, the lien claimant foreclosing the lien may be entitled to reasonable costs for removing any improvement or for restoring the property to its original condition.

History. Laws 1877, p. 77, § 3; R.S. 1887, § 1519; R.S. 1899, § 2891; C.S. 1910, § 3801; C.S. 1920, § 4864; R.S. 1931, § 66-506; C.S. 1945, § 55-203; W.S. 1957, § 29-6; W.S. 1977, § 29-2-104 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2010, ch. 92, § 2.

Cross references. —

As to priority of lien, see § 29-1-305 .

The 2010 amendment, effective July 1, 2011, substituted “lien claimant” for “person” near the beginning; deleting “provided by this chapter” following “enforcing the lien”; inserted “and real property”; substituted “real property” for “land”; inserted “In addition to attorneys' fees and costs” in the second sentence; and substituted “lien claimant” for “party.”

Lien of chattel mortgage on a mining claim, machinery and equipment is superior to a miner's lien for work which was performed after the filing of the mortgage. Prugh v. Imhoff, 44 Wyo. 143, 9 P.2d 152, 1932 Wyo. LEXIS 14 (Wyo. 1932).

Conveyance before judgment, but subsequent to lien. —

A sale under judgment in action to enforce mechanic's lien takes priority over conveyance made by owner of property before rendition of judgment but subsequent to attaching of the lien, although the judgment does not describe the property. Lee v. Cook, 2 Wyo. 312, 1880 Wyo. LEXIS 11 (Wyo. 1880).

Sale of structure. —

Under this section judgment ordering sale under execution of a structure to which a lien for materials attaches is valid and enforceable, though structure cannot be removed from the land, as the purchaser is authorized to do within a reasonable time, since he may agree with owner to leave property on the land. Clarke v. Shoshoni Lumber Co., 31 Wyo. 205, 224 P. 845, 1924 Wyo. LEXIS 18 (Wyo. 1924), writ of error dismissed, 276 U.S. 595, 48 S. Ct. 302, 72 L. Ed. 722, 1928 U.S. LEXIS 118 (U.S. 1928).

Mechanic's lien against house built upon mortgaged land. —

If a contractor, under contract with the owner of the equity of redemption on mortgaged land, builds a new house upon the land, he has a mechanic's lien against the house, and the house may be sold and removed by the purchaser; for this preserves to the mortgagee all the security he formerly had and secures, as far as possible, the payment to the contractor for the work and materials he used in building the house. Sargent v. Delgado, 492 P.2d 193, 1972 Wyo. LEXIS 212 (Wyo. 1972).

Superintendent's lien for services. —

Superintendent and engineer in charge of construction of plant who also performed work and labor was entitled to lien for his salary. Continental & Commercial Trust & Sav. Bank v. North Platte Valley Irr. Co., 219 F. 438, 1915 U.S. App. LEXIS 1639 (8th Cir. Wyo. 1915).

Timely filing. —

Where last materials for job were delivered June 15, 1912, though not actually used and accounts were kept open continuously until that date, lien statement was properly filed within 90 days from that time. Continental & Commercial Trust & Sav. Bank v. North Platte Valley Irr. Co., 219 F. 438, 1915 U.S. App. LEXIS 1639 (8th Cir. Wyo. 1915).

Cited in

Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980).

Law reviews. —

See note “Priority Between Mortgages and Mechanics' Liens,” 13 Wyo. L.J. 239 (1959).

Am. Jur. 2d, ALR and C.J.S. references. —

Priority as between artisans' lien and chattel mortgage, 36 ALR2d 229.

Priority as between purchase-money mortgage and mechanic's lien, 73 ALR2d 1407.

Advances made under previously executed mortgage, 80 ALR2d 179.

Priorities as between previously perfected security interest and repairman's lien on motor vehicle under Uniform Commercial Code, 69 ALR3d 1162.

§ 29-2-104. Lien upon leaseholds; foreclosure; removal of improvements.

  1. Every building or improvement or any material furnished for use upon any leased property shall subject the leasehold interest to the lien provided by this chapter.
  2. A lien claimant may:
    1. Proceed to foreclose a lien upon the leasehold subject to the limitations of W.S. 29-2-101(a), (b) and (c); or
    2. Seek an order from the court for removal of any improvement. Upon establishing that the property will be in the same or similar condition as prior to the performance of the work for which the lien is claimed, the court may authorize the removal. The party foreclosing the lien may be entitled to reasonable costs for removing any improvements or for restoring the property to its previous condition.

History. Laws 1877, p. 78, § 4; R.S. 1887, § 1520; R.S. 1899, § 2892; C.S. 1910, § 3802; C.S. 1920, § 4865; R.S. 1931, § 66-507; C.S. 1945, § 55-204; W.S. 1957, § 29-9; W.S. 1977, § 29-2-107 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Cited in

Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980).

Am. Jur. 2d, ALR and C.J.S. references. —

Enforceability of mechanic's lien attached to leasehold estate against landlord's fee, 74 ALR3d 330.

§ 29-2-105. Lien for improvements placed by tenant authorized by landlord.

  1. Notwithstanding the definition of “owner”, if a tenant places any improvements either within or on the outside of any building or on the real property on which the building stands, the person doing any work or furnishing any material for the purpose of the improvement shall have a lien upon the landlord’s and the tenant’s interest in the building and real property as provided by this chapter if:
    1. The landlord has agreed to pay the costs of the improvement; or
    2. The improvements are specifically authorized by the landlord.

History. Laws 1877, p. 81, § 22; R.S. 1887, § 1538; R.S. 1899, § 2909; C.S. 1910, § 3819; C.S. 1920, § 4883; R.S. 1931, § 66-525; C.S. 1945, § 55-223; W.S. 1957, § 29-10; W.S. 1977, § 29-2-108 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2010, ch. 92, § 2.

The 2010 amendment, effective July 1, 2011, in the introductory language of (a), substituted “real property” for “land” twice; and inserted “landlord's and the tenant's interest in the.”

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

Agency of lessee. —

Under lease whereby the lessor obligates lessee as part of consideration to make permanent and substantial improvements on a building, to make it usable, and lessee fails to pay materialmen for materials furnished, latter may claim lien upon the leased premises, lessee under such a lease being presumed to be agent of the lessor. Jordan v. Natrona Lumber Co., 52 Wyo. 393, 75 P.2d 378, 1938 Wyo. LEXIS 34 (Wyo. 1938).

Construction. —

Term “specifically authorized,” as used in Wyo. Stat. Ann. § 29-2-105(a)(ii), requires a showing of an agency relationship between a landlord and tenant before a mechanic's lien may attach to the landlord's property. Redco Constr. v. Profile Props., LLC, 2012 WY 24, 271 P.3d 408, 2012 Wyo. LEXIS 25 (Wyo. 2012).

Agency relationship required. —

Summary judgment was properly awarded to a landlord in a contractor's action to foreclose a mechanic's lien because the trial court correctly interpreted Wyo. Stat. Ann. § 29-2-105(a)(ii) to require a finding of agency between the landlord and a tenant before a mechanic's lien could attach to the landlord's property for work performed at the tenant's behest. Redco Constr. v. Profile Props., LLC, 2012 WY 24, 271 P.3d 408, 2012 Wyo. LEXIS 25 (Wyo. 2012).

Cited in

Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980).

Am. Jur. 2d, ALR and C.J.S. references. —

Right to mechanic's lien against fixtures installed upon property under lease, 42 ALR2d 685.

§ 29-2-106. When statement lien to be filed; rights of subcontractor not abridged by contract between owner and contractor; agreement to extend filing period.

  1. Except as provided in subsection (c) of this section, any contractor asserting a lien under this chapter shall file his lien statement within one hundred fifty (150) days and every other person asserting a lien under this chapter shall file within one hundred twenty (120) days:
    1. Of the earlier of:
      1. After the last day when work was performed or materials furnished under contract;
      2. From the date of substantial completion of the project on which work was performed or materials were furnished under contract; or
    2. With respect to a subcontractor, after the last day he performed work at the direction of the contractor or other person authorized to provide direction.
  2. No contract made between the record owner and the contractor shall be construed to affect or restrict the right of any subcontractor or materialman to file a lien.
  3. The record owner may record a notice of substantial completion of the project in the records of the county clerk in the county where the project is located. If a notice of substantial completion of the project is recorded under this subsection, the date the notice is recorded shall be presumed to be the date of substantial completion of the project. After the notice has been duly recorded, the record owner shall send a copy of the notice within five (5) days to all contractors, subcontractors and materialmen who provided the record owner with preliminary notice pursuant to W.S. 29-2-112 . The notice shall not extend the date by which a lien statement shall be filed as may otherwise be provided in this section. The time to file a lien statement by any contractor, subcontractor or materialman shall not be affected if the record owner fails to send the notice of substantial completion of the project.
  4. The notice of substantial completion of the project shall refer to this section, provide the date of substantial completion of the project on the notice and state in bold face type: “This notice creates a rebuttable presumption that the period for filing a lien shall begin to run as of the date the notice was recorded. If the recipient of the notice has not been paid in full, any lien to be filed on the property to secure full payment shall be filed by contractors within one hundred fifty (150) days of the date the notice was recorded and within one hundred twenty (120) days of the date the notice was recorded for materialmen.”
  5. Any party to a contract for which a lien may be filed may agree to an extension of the time within which the lien may be filed. The time agreed upon may not exceed twice the time within which the lien would have to be filed in accordance with subsection (a) of this section. The agreement shall be acknowledged before a notarial officer, and signed by the owner, the contractor and any other parties to the contract before it is valid. The agreement shall be filed with and recorded by the county clerk in the manner provided by W.S. 29-1-312 for a lien statement. The lien rights of persons not signing the agreement are not affected by it.
  6. A cooperative utility claiming a lien under W.S. 29-2-101(d) shall file its lien statement within one hundred eighty (180) days after the first date the provisions of W.S. 29-2-101(d)(i) and (ii) were met. The cooperative utility and its member may agree to an extension of the time in which the lien may be filed, but the agreement may not exceed a total time for filing the lien statement beyond three hundred sixty (360) days. Any agreement for an extension under this subsection shall otherwise comply with the requirements of subsection (e) of this section.

History. Laws 1877, p. 78, § 5; 1886, ch. 25, § 1; R.S. 1887, § 1521; Laws 1897, ch. 20, § 1; R.S. 1899, § 2893; C.S. 1910, § 3803; C.S. 1920, § 4866; R.S. 1931, § 66-508; C.S. 1945, § 55-205; W.S. 1957, § 29-11; W.S. 1977, § 29-2-109 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2007, ch. 193, § 1; 2008, ch. 20, § 2; 2010, ch. 92, § 2.

Cross references. —

See also § 29-2-109 and cross references thereunder.

The 2007 amendment, effective July 1, 2007, added (d).

The 2008 amendment, effective July 1, 2008, substituted “notarial officer” for “notary public” in the third sentence of (c).

The 2010 amendment, effective July 1, 2011, in the introductory language of (a), substituted “Except as provided in subsection (c) of this section, any” for “Every,” inserted “asserting a lien under this chapter” twice, substituted “one hundred fifty (150) days” for “one hundred twenty (120) days,” and substituted “one hundred twenty (120) days” for “ninety (90) days”; inserted “Of the earlier of:” in the introductory language of (a)(i); inserted (a)(i)(A) designation and redesignated former (a)(ii) and (a)(iii) as (a)(i)(B) and (a)(ii); in (a)(i)(B), inserted “of substantial completion of the project on which” and substituted “performed or materials were furnished under contract” for “substantially completed or substantial completion of the contract to furnish materials, whichever is earlier”; in (a)(ii), substituted “a subcontractor” for “an employee or subcontractor” and “the contractor or other person authorized to provide direction” for “his employer or contractor”; in (b), inserted “record” and substituted “or materialman” for “journeyman or worker”; added (c) and (d); redesignated former (c) and (d) as (e) and (f); substituted “ W.S. 29-1-312 ” for “ W.S. 29-1-301 ” in (e); substituted “subsection (e)” for “subsection (c)” in (f); and made related change.

Basic purpose of lien statutes is that they are intended to create a new means of securing the claims of particular classes of creditors and to prevent unjust enrichment arising from the enhancement in value of property from work and materials expended thereon which would otherwise go without payment. United Pac. Ins. Co. v. Martin & Luther Gen. Contractors, 455 P.2d 664, 1969 Wyo. LEXIS 142 (Wyo. 1969).

Basic principle underlying all mechanics' lien statutes is one of equity, that unconscionable and unjust enrichment should be prevented in the field of construction. United Pac. Ins. Co. v. Martin & Luther Gen. Contractors, 455 P.2d 664, 1969 Wyo. LEXIS 142 (Wyo. 1969).

Strict compliance with statutory requirements mandatory. —

Since the mechanic's lien is a statutory creature in derogation of the common law, strict compliance with statutory requirements is mandatory. Tottenhoff v. Rocky Mountain Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980). See, also, Sargent v. Delgado, 492 P.2d 193, 1972 Wyo. LEXIS 212 (Wyo. 1972).

To establish valid lien, there must be full compliance with statutory requirements. Foster Lumber Co. v. Hume, 645 P.2d 1176, 1982 Wyo. LEXIS 347 (Wyo. 1982).

Materialman may be contractor, and he is, in fact, a contractor if he furnished the material on a contract with the owner. Jordan v. Natrona Lumber Co., 52 Wyo. 393, 75 P.2d 378, 1938 Wyo. LEXIS 34 (Wyo. 1938).

Timely and proper action necessary. —

An incumbrance created during progress of construction is obtained with notice that the builder will be entitled to a superior lien providing only that timely and proper action is taken to establish the same. Sawyer v. Sawyer, 79 Wyo. 489, 335 P.2d 794, 1959 Wyo. LEXIS 17 (Wyo. 1959).

Lien claim must be filed within time limited by this section. Foster Lumber Co. v. Hume, 645 P.2d 1176, 1982 Wyo. LEXIS 347 (Wyo. 1982).

District court erred in enforcing a material lien a supplier filed against owners' property because the lien was not timely as a matter of law since it was not filed within ninety days of the substantial completion date the district court found; the earlier date of substantial completion the district court found and not the date the supplier last provided materials began the period during which it could file its lien statement. Bates v. Chi. Lumber Co., 2016 WY 58, 375 P.3d 732, 2016 Wyo. LEXIS 67 (Wyo. 2016).

Compromise valid on last day. —

In a dispute regarding a mechanics' lien, delivery of a lien waiver on the last day that a lien statement could have been filed constituted a compromise and settlement because the elements of a contract were satisfied; economic duress was rejected as a defense because, considering the relatively small amount of money involved, a reasonable alternative, expedited review under Wyo. Stat. Ann. § 29-1-311 , existed. Dobson v. Portrait Homes, Inc., 2005 WY 95, 117 P.3d 1200, 2005 Wyo. LEXIS 114 (Wyo. 2005).

Company furnishing materials for construction, but not installing materials, deemed “materialman,” not “contractor.” —

A company who entered a contract with the record owner of real property to furnish materials for the construction of a home on the property, but installed no materials into the new home, was a “materialman,” not a “contractor,” and had to file its lien statement within the 90-day time period provided by subsection (a). Weyerhaeuser Co. v. Walters, 707 P.2d 733, 1985 Wyo. LEXIS 585 (Wyo. 1985).

Lien not abrogated when owner prevents completion. —

Where an improvement is abandoned by the owner or where the completion is otherwise rendered impossible by the owner, the right to a lien is not abrogated. Engle v. First Nat'l Bank, 590 P.2d 826, 1979 Wyo. LEXIS 362 (Wyo. 1979).

Completion of contract causes debt to accrue. Engle v. First Nat'l Bank, 590 P.2d 826, 1979 Wyo. LEXIS 362 (Wyo. 1979).

Accrual of debt when restraining order prevents completion. —

The bank's action in obtaining a restraining order effectively prevented completion, and the debt accrued at such time as the parties gained knowledge of the restraining order. Engle v. First Nat'l Bank, 590 P.2d 826, 1979 Wyo. LEXIS 362 (Wyo. 1979).

Inclusion in description of more land than lien may attach does not vitiate lien upon so much of the land as the lien may attach. Engle v. First Nat'l Bank, 590 P.2d 826, 1979 Wyo. LEXIS 362 (Wyo. 1979).

Superintendent's lien for services. —

Superintendent and engineer in charge of construction of plant who also performed work and labor was entitled to lien for his salary. Continental & Commercial Trust & Sav. Bank v. North Platte Valley Irr. Co., 219 F. 438, 1915 U.S. App. LEXIS 1639 (8th Cir. Wyo. 1915).

Date of completion starts running of period for filing. Frontier Plumbing & Heating Co. v. Fitch, 480 P.2d 398, 1971 Wyo. LEXIS 197 (Wyo. 1971).

Where last materials for job were delivered June 15, 1912, though not actually used, and accounts were kept open continuously until that date, lien statement was properly filed within 90 days from that time. Continental & Commercial Trust & Sav. Bank v. North Platte Valley Irr. Co., 219 F. 438, 1915 U.S. App. LEXIS 1639 (8th Cir. Wyo. 1915).

And performing omitted part of contract cannot extend it. —

When a building is substantially complete and is accepted by the owner, the contractor cannot thereafter, at his own instance, perform some omitted part of the contract and thereby extend the period for filing the lien. Arch Sellery, Inc. v. Simpson, 346 P.2d 1068, 1959 Wyo. LEXIS 48 (Wyo. 1959).

A contractor cannot after completing work, at his own instance and against the will of the owner, perform some part that was called for in the contract, but which had been omitted in the construction, and thereby extend the period for filing his lien. Frontier Plumbing & Heating Co. v. Fitch, 480 P.2d 398, 1971 Wyo. LEXIS 197 (Wyo. 1971).

But supplementary work may extend lien. —

Custom, usage and practice in the building industry can serve to show that supplementary work on a building contract done within the 90-day limitation fixed by the legislature for filing a lien under this section was in fact considered an integral part of the contract by the parties, thus extending the lien. Arch Sellery, Inc. v. Simpson, 360 P.2d 911, 1961 Wyo. LEXIS 87 (Wyo. 1961).

Determination by trier. —

Generally it is for the trier to determine whether the additional work was minor and casual or long after the job was completed. Frontier Plumbing & Heating Co. v. Fitch, 480 P.2d 398, 1971 Wyo. LEXIS 197 (Wyo. 1971).

It is for the trier to determine whether additional work is minor and incidental, rather than substantial, and his determination will not be disturbed if the evidence reasonably supports him. Frontier Plumbing & Heating Co. v. Fitch, 480 P.2d 398, 1971 Wyo. LEXIS 197 (Wyo. 1971).

Mechanical lien held invalid and unenforceable because of premature filing where a notice of lien was filed prior to the passage of 60 days from the installation of material needed for completion of the job. Tottenhoff v. Rocky Mountain Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980).

Limitation in bond on commencement of action. —

Building contractor's bond, contract and facts must be considered to determine whether limitation in bond on commencement of action is reasonable. American Sur. Co. v. Broadway Improvement & Inv. Co., 39 Wyo. 195, 271 P. 19, 1928 Wyo. LEXIS 100 (Wyo. 1928), reh'g denied, 39 Wyo. 195, 271 P. 19, 1929 Wyo. LEXIS 59 (Wyo. 1929).

Contractor's bond provision against suit on bond later than specified date held applicable only if building were completed by date specified. American Sur. Co. v. Broadway Improvement & Inv. Co., 39 Wyo. 195, 271 P. 19, 1928 Wyo. LEXIS 100 (Wyo. 1928), reh'g denied, 39 Wyo. 195, 271 P. 19, 1929 Wyo. LEXIS 59 (Wyo. 1929).

Discrepancy in lien statement as to date materials were furnished was immaterial where no one was mislead thereby, though the statement would have been filed too late if the date mentioned therein had been the correct date. Phelan v. Cheyenne Brick Co., 26 Wyo. 493, 188 P. 354, 1920 Wyo. LEXIS 10 (Wyo.), reh'g denied, 26 Wyo. 493, 189 P. 1103, 1920 Wyo. LEXIS 11 (Wyo. 1920).

Amendment of pleading to assert mechanic's lien as a contractor instead of as subcontractor made more than 6 months after filing of lien statement held barred under this section. McDonald Amusement Co. v. Fleming Bros. Lumber Co., 35 F.2d 638, 1929 U.S. App. LEXIS 3035 (10th Cir. Wyo. 1929) (decided prior to Rule 15, W.R.C.P.).

Item to be subject of lien. —

Lien for materials furnished cannot be computed from date of last item in claimant's account unless such item was the subject of a lien. Mawson-Peterson Lumber Co. v. Sprinkle, 59 Wyo. 334, 140 P.2d 588, 1943 Wyo. LEXIS 18 (Wyo. 1943).

Stove parts, not being parts of fixture, from face of account are not lienable; to bring filing of lien statement within 4 month period, burden to show items lienable is upon claimant, by proof thereof that is reasonably clear. Mawson-Peterson Lumber Co. v. Sprinkle, 59 Wyo. 334, 140 P.2d 588, 1943 Wyo. LEXIS 18 (Wyo. 1943).

Where lien claimant failed to establish that “stove parts,” which on their face are not lienable, were lienable items in his case, judgment for claimant was not sustained. Mawson-Peterson Lumber Co. v. Sprinkle, 59 Wyo. 334, 140 P.2d 588, 1943 Wyo. LEXIS 18 (Wyo. 1943).

Provisions for retaining percentages. —

Building contract and surety bond provisions for retaining percentages held inapplicable to building material on premises when contract was executed. American Sur. Co. v. Broadway Improvement & Inv. Co., 39 Wyo. 195, 271 P. 19, 1928 Wyo. LEXIS 100 (Wyo. 1928), reh'g denied, 39 Wyo. 195, 271 P. 19, 1929 Wyo. LEXIS 59 (Wyo. 1929).

Lien statement insufficient for failure to describe materials furnished. —

Where no attempt is made in the lien statement to describe the “materials and supplies” furnished, nor any indication given of the type of services rendered, the lien statement is insufficient to satisfy the statutory requirement of a “just and true account of the demand.” Union Mfg. & Supply Co. v. Groff, 624 F.2d 133, 1980 U.S. App. LEXIS 16585 (10th Cir. 1980).

Inaccuracies in lien statement. —

A lien statement may be regarded as just and true, so as not to vitiate the entire lien, even if it contains mistakes or errors of omission and includes nonlienable items of charge, if those inaccuracies of fact are unintentional and are the result of honest inadvertence, accident or oversight and do not result from deliberate intention or design. United Pac. Ins. Co. v. Martin & Luther Gen. Contractors, 455 P.2d 664, 1969 Wyo. LEXIS 142 (Wyo. 1969).

In the absence of any showing of fraud or bad faith, and where the nonlienable items are separable from the balance of the account and their inclusion is through inadvertence, or is the result of an honest mistake and no one has been injured or misled thereby, it is ruled that such inclusion does not invalidate the entire lien. United Pac. Ins. Co. v. Martin & Luther Gen. Contractors, 455 P.2d 664, 1969 Wyo. LEXIS 142 (Wyo. 1969).

But when nonlienable items are included in a lien statement deliberately, knowingly and intentionally, then the account so filed may not be regarded as just and true within the meaning of this section and can form no basis for the adjudication and establishment of a lien for any part of the account. United Pac. Ins. Co. v. Martin & Luther Gen. Contractors, 455 P.2d 664, 1969 Wyo. LEXIS 142 (Wyo. 1969).

Mistaken inclusion of nonlienable items does not invalidate lien. —

In the absence of any showing of fraud or bad faith, and where nonlienable items are separable from the balance of an account and their inclusion is through inadvertence or is the result of an honest mistake and no one has been injured or misled thereby, such inclusion does not invalidate the entire mechanics' lien. Kirby Bldg. Sys. v. Independence Partnership No. One, 634 P.2d 342, 1981 Wyo. LEXIS 376 (Wyo. 1981).

Burden of separating nonlienable items. —

If lienable items can be separated from those which are nonlienable in a foreclosure proceeding, the burden of doing so is on the claimant. United Pac. Ins. Co. v. Martin & Luther Gen. Contractors, 455 P.2d 664, 1969 Wyo. LEXIS 142 (Wyo. 1969).

Word “owner” in this section means the owner at the time the statement is made and filed. Davis v. Big Horn Lumber Co., 14 Wyo. 517, 85 P. 980, 1906 Wyo. LEXIS 29 (Wyo. 1906).

The word “owner” means the party in interest who is the source of authority for the improvement, and one who deals with such party directly is contracting with the owner, not a subcontractor, and is an original contractor. Jordan v. Natrona Lumber Co., 52 Wyo. 393, 75 P.2d 378, 1938 Wyo. LEXIS 34 (Wyo. 1938).

Where wife not made party. —

Subcontractor was not entitled to foreclose mechanic's lien against property held by husband and wife by entirety by virtue of deed recorded 2 months after filing of lien statement in which wife was not named where wife was not made party to suit to foreclose until 3 years after filing lien statement. Peters v. Dona, 49 Wyo. 306, 54 P.2d 817, 1936 Wyo. LEXIS 45 (Wyo. 1936).

Contract authorizing filing of lien may be either express or implied. —

In order to authorize the filing of a lien under § 29-2-102 , the existence of a contract is necessary, but it may be either express or implied. Arch Sellery, Inc. v. Simpson, 346 P.2d 1068, 1959 Wyo. LEXIS 48 (Wyo. 1959).

Neglect to require bond. —

Neglect of school board to require building contractor to give bond against mechanics' liens, provided for by the contract, did not make school district liable to the subcontractor for material furnished and used on the building. Peters v. Killibrew, 24 Wyo. 53, 154 P. 996, 1916 Wyo. LEXIS 9 (Wyo. 1916).

Quoted in

American Bldgs. Co. v. Wheelers Stores, 585 P.2d 845, 1978 Wyo. LEXIS 239 (Wyo. 1978); P & N Invs, LLC v. Frontier Mall Assocs., LP, 2017 WY 62, 395 P.3d 1101, 2017 Wyo. LEXIS 62 (Wyo. 2017).

Cited in

Big Horn Lumber Co. v. Davis, 14 Wyo. 455, 84 P. 900, 1906 Wyo. LEXIS 21 (1906).

Am. Jur. 2d, ALR and C.J.S. references. —

Validity and effect of contract against mechanics' liens, 76 ALR2d 1087.

Contract between owner and principal contractor against lien as affecting right of subcontractor's and materialman's lien, 76 ALR2d 1087.

Provision against mechanic's lien in contract between principal contractor and subcontractor as affecting subcontractor's lien, 76 ALR2d 1087, 75 ALR3d 505.

Abandonment of construction or contract as affecting time for filing mechanics' liens, 52 ALR3d 797.

Release or waiver of mechanic's lien by general contractor as affecting rights of subcontractor or materialman, 75 ALR3d 505.

Liability of purchaser of real estate on mechanic's lien based on goods or labor supplied to vendor but filed after title passed, 33 ALR4th 1017.

Unjust enrichment of landowner based on adjoining landowner's construction, improvement, or repair of commonly used highway, street, or bridge, 22 ALR5th 800.

Timeliness of notice to public works contractor on federal project, of indebtedness for labor or materials furnished, 69 ALR Fed 600.

§ 29-2-107. Notice of intention to file lien.

  1. Before filing a lien pursuant to this chapter a lien claimant shall send written notice to the record owner or his agent of any claim against real property, a building or an improvement stating the amount of any claim and from whom it is due. The notice shall be sent no later than twenty (20) days prior to filing a lien statement.
  2. The notice under this section shall be in substantially the same format and contain the same information as the notice form specified in W.S. 29-10-102 . The notice forms shall be made available and may be obtained at the county clerk’s office of each county.

History. C.L. 1876, ch. 81, § 18; R.S. 1887, § 1534; R.S. 1899, § 2905; C.S. 1910, § 3815; C.S. 1920, § 4879; R.S. 1931, § 66-521; C.S. 1945, § 55-219; W.S. 1957, § 29-12; W.S. 1977, § 29-2-110 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2010, ch. 92, § 2.

The 2010 amendment, effective July 1, 2011, in (a), substituted “a lien claimant shall send written notice to the record owner or his agent of any claim against real property, a building or an improvement” for “every person shall give ten (10) days notice to the owner or his agent in writing of any claim against a building or an improvement or for materials furnished” and added second sentence; and added (b).

Main object of preliminary notice of lienable demand, which this section requires a subcontractor to give to a property owner, is to warn the latter against paying the original contractor while outstanding claims exist in favor of laborers and materialmen. Kirby Bldg. Sys. v. Independence Partnership No. One, 634 P.2d 342, 1981 Wyo. LEXIS 376 (Wyo. 1981).

Notice to put reasonable person on notice of claim. —

Notice of a mechanics' lien, absent a showing of bad faith, must contain sufficient information so as to put a reasonable person on notice of the nature of the claim. Kirby Bldg. Sys. v. Independence Partnership No. One, 634 P.2d 342, 1981 Wyo. LEXIS 376 (Wyo. 1981).

To assert inadequacy of notice, party must establish that he has been misled. Kirby Bldg. Sys. v. Independence Partnership No. One, 634 P.2d 342, 1981 Wyo. LEXIS 376 (Wyo. 1981).

Notice sent to present owners of property. —

Inasmuch as the lien claimant failed to comply with the statutory requirement of giving proper notice to the owners of the property at the time the notice of intention to file lien was sent, although these parties were not the record owners at the time the claimant entered into a contract to supply materials to the then record owner, the lien was ineffective. Weyerhaeuser Co. v. Walters, 707 P.2d 733, 1985 Wyo. LEXIS 585 (Wyo. 1985).

Evidence of notice. —

In suit to enforce mechanic's lien, a stipulation, made to avoid continuance, that an absent witness, if present, would testify that notice of the claim and of the intention to file a lien was served on defendants, of which notice a copy was attached and marked “B,” constituted sufficient evidence of notice of intention to file lien, without formally offering the notice in evidence. Phelan v. Cheyenne Brick Co., 26 Wyo. 493, 188 P. 354, 1920 Wyo. LEXIS 10 (Wyo.), reh'g denied, 26 Wyo. 493, 189 P. 1103, 1920 Wyo. LEXIS 11 (Wyo. 1920).

Notice requirement waived unless raised at trial. —

The ten days notice is a requirement of this section, but it is waived unless the issue is raised in the trial court. Schaefer v. Lampert Lumber Co., 591 P.2d 1225, 1979 Wyo. LEXIS 382 (Wyo. 1979).

Where wife not made party. —

Subcontractor was not entitled to foreclose mechanic's lien against property held by husband and wife by entirety through deed recorded 2 months after filing of lien statement wherein wife was not named and wife was not made party to foreclosure suit until over 3 years after filing lien statement. Peters v. Dona, 49 Wyo. 306, 54 P.2d 817, 1936 Wyo. LEXIS 45 (Wyo. 1936).

Quoted in

Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980).

Cited in

Jordan v. Natrona Lumber Co., 52 Wyo. 393, 75 P.2d 378, 1938 Wyo. LEXIS 34 (1938); True v. Hi-Plains Elevator Mach., Inc., 577 P.2d 991, 1978 Wyo. LEXIS 281 (Wyo. 1978); Foster Lumber Co. v. Hume, 645 P.2d 1176, 1982 Wyo. LEXIS 347 (Wyo. 1982); Orcutt v. Shober Invs., Inc., 2003 WY 60, 69 P.3d 386, 2003 Wyo. LEXIS 75 (Wyo. 2003); Keith L. Dobson & Aspen Constr. Co. v. Portrait Homes, Inc., 2005 WY 95, 117 P.3d 1200, 2005 Wyo. LEXIS 114 (2005).

Am. Jur. 2d, ALR and C.J.S. references. —

Sufficiency of notice, claim or statement of mechanic's lien with respect to nature of work, 27 ALR2d 1169.

Sufficiency of notice, claim or statement of mechanic's lien with respect to description or location of real property, 52 ALR2d 12.

Sale of real property as affecting time for filing notice of or perfecting mechanic's lien as against purchaser's interest, 76 ALR2d 1163.

Time for filing notice or claim of mechanic's lien where claimant has contracted with general contractor and later contracts directly with owner, 78 ALR2d 1165.

Sufficiency of designation of owner in notice, claim or statement of mechanic's lien, 48 ALR3d 153.

Abandonment of construction or of contract as affecting time for filing mechanics' liens or time for giving notice to owner, 52 ALR3d 797.

Liability of purchaser of real estate on mechanic's lien based on goods or labor supplied to vendor but filed after title passed, 33 ALR4th 1017.

Unjust enrichment of landowner based on adjoining landowner's construction, improvement, or repair of commonly used highway, street, or bridge, 22 ALR5th 800.

§ 29-2-108. Duty of contractor to defend action; liability of contractor to owner.

The contractor shall, at his own expense, defend any action brought by his employee, subcontractors hired by the contractor, their employees or by any suppliers of materials provided under contract in accordance with this chapter. During the pendency of the action the owner or his agent may withhold from the contractor the amount of money for which a lien is filed. If judgment is rendered against the owner or his property on the lien foreclosure, he may deduct from any amount due to the contractor the amount of the judgment and costs. If the owner has paid the contractor in full he may recover from the contractor any amount paid by the owner for which the contractor was originally liable.

History. C.L. 1876, ch. 81, § 19; R.S. 1887, § 1535; R.S. 1899, § 2906; C.S. 1910, § 3816; C.S. 1920, § 4880; R.S. 1931, § 66-522; C.S. 1945, § 55-220; W.S. 1957, § 29-17; W.S. 1977, § 29-2-115; Laws 1981, Sp. Sess., ch. 17, § 2; 2010, ch. 92, § 2.

The 2010 amendment, effective July 1, 2011, inserted “at his own expense” near the beginning and deleted “at his own expense” at the end of the first sentence.

Nature of lien foreclosure action. —

Even though the mechanics' lien statutes authorize the entry of personal judgments against the contractor-debtor under this section a lien foreclosure action, resulting in such judgments, cannot be considered an action “for the recovery of money only, or specific real or personal property,” within the meaning of Rule 38 (a), W.R.C.P. An action for foreclosure of a mechanic's lien is an equitable proceeding and, as contemplated by Rule 38 (a), W.R.C.P., should be triable by the court without a jury. It is principally an action to bind the property of the owner whose premises have been improved by the labor or materials furnished by the lien claimant for that purpose. True v. Hi-Plains Elevator Mach., 577 P.2d 991, 1978 Wyo. LEXIS 281 (Wyo. 1978).

Owner's right to have contractor made party. —

The provisions of this section were evidently incorporated for the owner's protection, and to accomplish the full purpose thereof, the owner has a clear right to insist that the contractor be made a party, if possible, so that he may be bound by the judgment. While no personal judgment can be rendered against the contractor in such a suit unless there has been service of summons upon him within the state, he may nevertheless, if a nonresident of the state, be brought in as a party, for the statutes provided for constructive service in such a case pursuant to § 29-2-116.True v. Hi-Plains Elevator Mach., 577 P.2d 991, 1978 Wyo. LEXIS 281 (Wyo. 1978).

Because a lien foreclosure action by a subcontractor was an in rem action against the owner and did not require the presence of either the bankrupt contractor or its alleged joint venturer, Wyo. R. Civ. P. 19 and this section did not preclude the district court from granting summary judgment to the subcontractor in their absence; moreover, the automatic stay of 11 U.S.C.S. § 362(a) did not apply to the proceedings against the solvent owner. KM Upstream, LLC v. Elkhorn Constr., Inc., 2012 WY 79, 278 P.3d 711, 2012 Wyo. LEXIS 84 (Wyo. 2012).

Time for foreclosing mechanic's lien against owner not stayed by contractor's bankruptcy. —

A contractor is not an indispensable party to a lien foreclosure unless the owner of the property subject to lien wants him joined. Since the employees of a contractor who filed for bankruptcy untimely filed their suit for foreclosure of a mechanic's lien, and since the contractor was not an indispensable party, the automatic stay granted the contractor by federal law did not stay foreclosure against the owner under either state or federal law, and the employees had no lien at the time of filing their action. Hamel v. American Continental Corp., 713 P.2d 1152, 1986 Wyo. LEXIS 471 (Wyo. 1986).

Cited in

American Sur. Co. v. Broadway Improvement & Inv. Co., 39 Wyo. 195, 271 P. 19, 1928 Wyo. LEXIS 100 (1928); Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980).

§ 29-2-109. Limitation of actions; duration of liens.

All actions to foreclose or enforce a lien under this chapter shall be commenced within one hundred eighty (180) days after the filing of the lien statement. No lien shall continue to exist except by virtue of the provisions of this chapter for more than one hundred eighty (180) days after the lien is filed unless an action to foreclose the lien is instituted.

History. Laws 1877, p. 80, § 15; 1886, ch. 25, § 3; R.S. 1887, § 1531; R.S. 1899, § 2902; C.S. 1910, § 3812; C.S. 1920, § 4876; R.S. 1931, § 66-518; C.S. 1945, § 55-216; W.S. 1957, § 29-25; W.S. 1977, § 29-2-123; Laws 1981, Sp. Sess., ch. 17, § 2.

Cross references. —

For other important time periods under this title, see also §§ 29-2-106 , 29-3-109 , 29-5-103 , and 29-5-105 .

Superintendent's lien for services. —

Superintendent and engineer in charge of construction of plant who also performed work and labor was entitled to lien for his salary. Continental & Commercial Trust & Sav. Bank v. North Platte Valley Irr. Co., 219 F. 438, 1915 U.S. App. LEXIS 1639 (8th Cir. Wyo. 1915).

Timely filing of lien statement. —

Where last materials for job were delivered June 15, 1912, though not actually used, and accounts were kept open continuously until that date, lien statement was properly filed within 90 days from that time. Continental & Commercial Trust & Sav. Bank v. North Platte Valley Irr. Co., 219 F. 438, 1915 U.S. App. LEXIS 1639 (8th Cir. Wyo. 1915).

Lapse of lien. —

Unless suit to foreclose mechanic's lien is instituted within 6 months against owner of the premises, the lien lapses and the court is without jurisdiction to proceed with the foreclosure. Peters v. Dona, 49 Wyo. 306, 54 P.2d 817, 1936 Wyo. LEXIS 45 (Wyo. 1936).

Indispensible party's bankruptcy tolls lien foreclosurer. —

Where a corporate debtor-landowner was an indispensable party to a foreclosure action against nondebtor mortgage holders, an architect's amended petition to foreclose his lien was subject to the automatic stay of the federal Bankruptcy Code, and this section was tolled during the pendency of the debtor's bankruptcy proceedings. Diamond Hill Inv. Co. v. Shelden, 767 P.2d 1005, 1989 Wyo. LEXIS 15 (Wyo. 1989).

Time for foreclosing mechanic's lien against owner not stayed by contractor's bankruptcy. —

A contractor is not an indispensable party to a lien foreclosure unless the owner of the property subject to lien wants him joined. Since the employees of a contractor who filed for bankruptcy untimely filed their suit for foreclosure of a mechanic's lien, and since the contractor was not an indispensable party, the automatic stay granted the contractor by federal law did not stay foreclosure against the owner under either state or federal law, and the employees had no lien at the time of filing their action. Hamel v. American Continental Corp., 713 P.2d 1152, 1986 Wyo. LEXIS 471 (Wyo. 1986).

Where wife not made party. —

Subcontractor was not entitled to foreclose mechanic's lien against property held by husband and wife by entirety through deed recorded 2 months after filing of lien statement wherein wife was not named and wife was not made party to foreclosure suit until over 3 years after filing lien statement. Peters v. Dona, 49 Wyo. 306, 54 P.2d 817, 1936 Wyo. LEXIS 45 (Wyo. 1936).

Mortgagee interest holder, not sued within limitation period, not affected by lien. —

No action was brought within 180 days after the filing of the lien statement to foreclose the interest of the mortgage interest holder, and thus the lien could not affect its interest. The fact that a suit was commenced within 180 days against the owners of the property, to whom the statute of limitations defense was not available, was irrelevant. Seafirst Mortgage Corp. v. Specialty Concrete Constr., 708 P.2d 1245, 1985 Wyo. LEXIS 607 (Wyo. 1985).

Amendment of pleading to assert mechanic's lien as a contractor instead of as subcontractor made more than 6 months after filing of lien statement held barred under this section. McDonald Amusement Co. v. Fleming Bros. Lumber Co., 35 F.2d 638, 1929 U.S. App. LEXIS 3035 (10th Cir. Wyo. 1929) (decided prior to Rule 15, W.R.C.P.).

Cited in

Tottenhoff v. Rocky Mt. Constr. Co., 609 P.2d 464, 1980 Wyo. LEXIS 258 (Wyo. 1980); Miller v. State, 732 P.2d 1054, 1987 Wyo. LEXIS 395 (Wyo. 1987).

§§ 29-2-110 and 29-2-111. [Repealed.]

Repealed by Laws 2010, ch. 92, § 3.

Editor's notes. —

The repealed section, which derived from Laws 1989, ch. 177, § 1, related to notice to owner; limitations; condition precedent to lien.

Repeal effective July 1, 2011. —

Pursuant to Laws 2010, ch. 92, § 5, this section is repealed effective July 1, 2011.

Conflicting legislation. —

Laws 2004, ch. 130, § 3, provides: “Any other act adopted by the Wyoming legislature during the same session in which this act is adopted shall be given precedence and shall prevail over the amendments in this act to the extent that such acts are in conflict with this act.”

§ 29-2-112. Preliminary notices.

  1. With respect to perfecting the right to file a construction lien under this chapter, the following preliminary notice requirements shall apply:
    1. The contractor, subcontractor and materialman shall send written notice to the record owner or his agent, of the right to assert a lien against the property for which services or materials are provided if the contractor, subcontractor or materialman is not paid, and the right of the owner or contractor to obtain a lien waiver upon payment for services or materials. Each subcontractor and materialman shall provide a copy of the written notice to the contractor for which the subcontractor or materialman is providing services or materials;
    2. Any notice required under this section shall be sent:
      1. By the contractor prior to receiving any payment from owner, including advances;
      2. By the subcontractor or materialman within thirty (30) days after first providing services or materials to the construction project.
    3. Failure to send the notice required under this section within the time specified shall bar the right of a contractor, subcontractor or materialman to assert a lien;
    4. The notice required under this section shall be in substantially the same format and contain the same information as the notice contained in W.S. 29-10-101 . The form shall be made available and may be obtained at the county clerk’s office of each county.

History. Laws 2010, ch. 92, § 1.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

Cited in

Bates v. Chi. Lumber Co., 2016 WY 58, 375 P.3d 732, 2016 Wyo. LEXIS 67 (Wyo. 2016).

Stated in

CSC Grp. Holdings, LLC v. Automation & Elecs., Inc., 2016 WY 26, 368 P.3d 302, 2016 Wyo. LEXIS 27 (Wyo. 2016).

§ 29-2-113. Identity of record owner or his agent provided.

The contractor shall provide to subcontractors and materialmen at the time of contracting with them the name and address of the record owner and his agent, if applicable, and legal description of the site of the project on which work will be performed or materials furnished.

History. Laws 2010, ch. 92, § 1.

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

Chapter 3 Mines, Quarries, Oil, Gas or Other Wells

Editor's notes. —

There is no article 2 in this chapter as it appears in the printed acts.

Am. Jur. 2d, ALR and C.J.S. references. —

38 Am. Jur. 2d Gas and Oil § 1 et seq.; 51 Am. Jur. 2d Liens § 1 et seq; 53A Am. Jur. 2d Mines and Minerals §§ 367 to 370.

Excessiveness or adequacy of attorneys' fees in matters involving real estate—modern cases, 10 ALR5th 448.

Article 1. In General

§ 29-3-101. Definitions.

  1. As used in this chapter:
    1. “Drilling” means open pit work, field processing, gasification, digging, shooting, torpedoing, perforating, fracturing, testing, logging, acidizing, cementing, completing or repairing;
    2. “Material” means casing, tanks, pipelines, fuel, machinery, equipment, appliances, buildings, structures, tools, bits or supplies. “Material” does not include drilling rigs or hoists or their integral component parts except wire lines.

History. Laws 1955, ch. 101, § 6; W.S. 1957, § 29-28; W.S. 1977, § 29-3-102 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

Cited in

KM Upstream, LLC v. Elkhorn Constr., Inc., 2012 WY 79, 278 P.3d 711, 2012 Wyo. LEXIS 84 (June 6, 2012).

§ 29-3-102. Nonimpairment of lien attached to estate less than fee or to equitable or legal contingent interest.

  1. If a lien as provided by this chapter attaches to an estate less than the fee, forfeiture of the estate shall not impair any lien which attaches prior to forfeiture as to material, appurtenances and fixtures previously located on the estate.
  2. If a lien provided in this chapter attaches to an equitable interest or to a legal interest contingent upon the happening of a condition subsequent, failure of the interest to ripen into legal title or failure of the condition subsequent shall not impair any lien as to material, appurtenances and fixtures located thereon to which the lien attached prior to the failure.

History. Laws 1955, ch. 101, § 5; W.S. 1957, § 29-27; W.S. 1977, § 29-3-101 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Lien may attach to an estate less than the fee. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

Applied in

Oxley v. Mine & Smelter Supply Co., 439 P.2d 661, 1968 Wyo. LEXIS 164 (Wyo. 1968).

Am. Jur. 2d, ALR and C.J.S. references. —

Oil and gas farmout agreements, 65 ALR5th 211.

§ 29-3-103. Extent of liens; generally.

  1. Every person who works upon or furnishes material, whether incorporated into the real property or not, under contract with the owner of any interest in real estate or with an agent, trustee or receiver of an owner has a lien to secure payment for:
    1. Constructing, altering, digging, drilling, driving, boring, operating, completing or repairing any wells, mines or quarries;
    2. Altering, repairing or constructing any oil derrick, oil tank or any pipelines;
    3. Transportation and related mileage charges plus interest from the date due;
    4. Advertising, selling and preparing for sale;
    5. Sheriff’s fees; and
    6. Attorney’s fees and other costs of collection.
  2. Notwithstanding subsection (a) of this section and W.S. 29-3-105(a)(iii) through (ix):
    1. If work is performed for or materials are furnished the owner of an estate less than a fee the lien granted by this chapter shall not extend to the underlying fee or royalty interest unless expressly provided by contract with the owner of the underlying fee or royalty interest;
    2. If work is performed for or materials furnished to the owner, part owner or lessee of the working interest in only a portion of the acreage covered by a lease, the lien granted by this chapter shall be restricted to that portion of the acreage; and
    3. If work is performed for, or materials furnished to the owners or an agent, trustee of [or] receiver of the owners of lands, leases or interests therein validly pooled or unitized by agreement of the owners thereof or by operation of law, the lien granted by this chapter shall extend to the lands, leases or interests so pooled or unitized.

History. Laws 1919, ch. 128, § 1; C.S. 1920, § 4830; R.S. 1931, § 66-604; C.S. 1945, § 55-401; Laws 1955, ch. 101, § 1; W.S. 1957, § 29-29; W.S. 1977, § 29-3-103 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2006, ch. 114, § 1.

The 2006 amendment, deleted “or” at the end of (a)(i).

Laws 2006, ch. 114, § 5, makes the act effective immediately upon completion of all acts necessary for a bill to become law as provided by art. 4, § 8, Wyo. Const. Approved March 24, 2006.

Conflicting legislation. —

Laws 2006, ch. 114, § 3, provides: “[A]ny other act adopted by the Wyoming legislature during the same session in which this act is adopted shall be given precedence and shall prevail over the amendments in this act to the extent that such acts are in conflict with this act.”

Basic purpose of lien statutes, which are in derogation of the common law, is to create a new means of securing claims of particular classes of creditors and to prevent unjust enrichment arising from enhancement of property from which work and materials expended thereon would otherwise go without payment. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Oil and gas lien laws, like other lien laws, are purely statutory. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

They must be strictly construed, and their scope cannot be extended by implication. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

The lien, if any, has to arise by statute and not by a series of provisions in a contract wherein the lien claimant is not a party. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

No lien can be created without a contract with an owner or part owner, either legal or equitable, upon the property upon which the lien is established. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

Subcontractor has no lien against leasehold unless contractor has an agreement with owner that the owner will pay for the services asserted in the lien. Adobe Oil & Gas Corp. v. Getter Trucking, 676 P.2d 560, 1984 Wyo. LEXIS 251 (Wyo. 1984).

Term “royalty interest” does not mean “landowner's royalty interest”; that would add something to this section which is not there. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

Intent of legislature was to restrict lien in case of oil well to leasehold estate of the party who contracts for the drilling. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

And lien does not extend to fee or royalty interest absent express contract provision. —

The proviso expressly provides that a lien shall not extend to the underlying fee or royalty interest unless expressly provided by contract. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

Overriding royalty not subject to lien. —

The term “overriding royalty” is defined as an interest in oil and gas production at the surface, free of the expense of production, and in addition to the usual landowner's royalty reserved to the lessor in an oil and gas lease. It is, first and foremost, a “royalty interest,” and the application of this section means a lien shall not extent to an overriding royalty interest. Cities Serv. Oil Co. v. Pubco Petroleum Corp., 497 P.2d 1368, 1972 Wyo. LEXIS 257 (Wyo. 1972).

Mechanic's lien may arise by implication from the relations and dealings of the parties whose interest are involved. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Similarity to equitable lien. —

The statutorily created mechanic's lien is akin to an “equitable lien,” which has been defined as a right, not existing at law, to have specific property applied, in whole or in part, to the payment of a particular class of debts which may be created by express contract which shows an intention to charge some particular property with a debt obligation. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Effect of previous entry of judgment in favor of lienholder. —

Where the holder of a mechanic's lien as a statutory lien creditor against a corporate debtor obtained a choate lien upon the proceeds of the debtor's share of the proceeds of production in the hands of a judgment creditor with writ of execution upon service of the statutory notice, the previous entry of judgment in favor of the mechanic lienholder on the lien claim did not deprive the holder of the priority benefit of the lien. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Lien for labor and materials furnished assignee of lease extends to oil, not land. —

A lien for labor and material furnished under a contract with the assignee of an oil and gas lease, together with its priority, extends to the oil, and the proceeds thereof, as distinguished from the land or leasehold. Pheister v. Ogden Smelting & Ref. Mills, 364 P.2d 1078, 1961 Wyo. LEXIS 120 (Wyo. 1961).

But is superior to prior mortgage as to oil not in possession of mortgagee. —

Where the mortgagee made no effort of any kind whatever to take possession or control of oil produced on a leasehold, or the proceeds thereof, up to the time when plaintiff's lien for labor and material furnished under a contract with the assignee of an oil and gas lease became effective, the lien of the plaintiff must be held to be prior and superior to the claim of the mortgagee insofar as the oil and the proceeds thereof are concerned. The date of priority, however, must be held to relate back only to the time when the work and labor of the plaintiff was completed. Pheister v. Ogden Smelting & Ref. Mills, 364 P.2d 1078, 1961 Wyo. LEXIS 120 (Wyo. 1961).

Relation back. —

Because a lien on production did not relate back to the time prior to the petition date under Wyoming law, a creditor’s postpetition actions did not fall within the scope and safeguards of the relation back exception; rather, these actions violated the automatic stay, as they would give rise to postpetition liens and cause interception of debtor receivables. Southland Royalty Co. LLC v. Halliburton Energy Servs. (In re Southland Royalty Co. LLC), 624 B.R. 331, 2021 Bankr. LEXIS 149 (Bankr. D. Del. 2021).

Resolution of a mechanic's lien claim did not make moot an oil and gas lien claim. —

Resolution of a mechanic's lien claim did not make moot an oil and gas lien claim because the two types of claims are very different, as shown by this section and Wyo. Stat. Ann. § 29-3-105 . KM Upstream, LLC v. Elkhorn Constr., Inc., 2012 WY 79, 278 P.3d 711, 2012 Wyo. LEXIS 84 (Wyo. 2012).

Contents of notice. —

Although in action to enforce lien, under this section, it is necessary to state that contract for labor or materials was made with owner, or someone acting under his authority, such statement is not necessary in notice of lien under § 29-3-108 (now see § 29-3-106 ). Craig v. Higgins, 31 Wyo. 166, 224 P. 668, 1924 Wyo. LEXIS 15 (Wyo.), different results reached on reh'g, 32 Wyo. 58, 228 P. 802, 1924 Wyo. LEXIS 46 (Wyo. 1924).

Limitations of lien. —

Where principal contractor furnished material to dig an oil well, for which leaseholder agreed to assign certain leases, persons furnishing materials to contractor were not entitled to lien, since § 29-3-113 (now see § 29-3-110 ) limited owner's liability to consideration expressed in contract, and this section and § 29-3-104 provide that materialman's lien right is limited to that of original contractor. National Supply Company-Midwest v. Weaver, 35 Wyo. 224, 248 P. 353, 1926 Wyo. LEXIS 15 (Wyo. 1926).

Attorneys' fees. —

This section clearly applies only to contract claims, and thus did not authorize plaintiff's recovery of attorneys' fees on its claim for unjust enrichment. Matheson Drilling, Inc. v. Padova, 5 P.3d 810, 2000 Wyo. LEXIS 122 (Wyo. 2000).

Cited in

Champlin Petro. Co. v. Mingo Oil Producers, 628 F. Supp. 557, 1986 U.S. Dist. LEXIS 29948 (D. Wyo. 1986); Burg v. Ruby Drilling Co., 783 P.2d 144, 1989 Wyo. LEXIS 230 (Wyo. 1989).

Law reviews. —

See note, “Oil and Gas Interests Subject to Wyoming Lien Laws,” 11 Wyo. L.J. 160.

Am. Jur. 2d, ALR and C.J.S. references. —

Oil and gas farmout agreements, 65 ALR5th 211.

§ 29-3-104. Extent of liens; persons furnishing material or work under contract.

Any person, who furnishes or rents any materials or provides any work under contract with any contractor or subcontractor shall have a lien on all the property on which the lien of the contractor may attach to the same extent as the contractor’s lien to secure payment.

History. Laws 1919, ch. 128, § 2; C.S. 1920, § 4831; R.S. 1931, § 66-605; C.S. 1945, § 55-402; Laws 1955, ch. 101, § 2; W.S. 1957, § 29-30; W.S. 1977, § 29-3-104 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Property held subject to materialmen's liens after principal contractor paid in full. —

The oil and gas leasehold estate and well of the owner may be subject to materialmen's liens for amounts owing from the principal contractor to materialmen when the owner paid the principal contractor in full, pursuant to the drilling contract, after the well was completed prior to receiving notice from the materialmen that they had not been paid by the principal contractor. Arnold v. American Pipe & Supply Co., 413 P.2d 874, 1966 Wyo. LEXIS 143 (Wyo. 1966).

Subcontractor has no lien against leasehold unless contractor has an agreement with owner that the owner will pay for the services asserted in the lien. Adobe Oil & Gas Corp. v. Getter Trucking, 676 P.2d 560, 1984 Wyo. LEXIS 251 (Wyo. 1984).

Cited in

National Supply Company-Midwest v. Weaver, 35 Wyo. 224, 248 P. 353, 1926 Wyo. LEXIS 15 (1926).

§ 29-3-105. Extent of liens; on oil, or proceeds thereof; notice to purchaser required; effect of notice; purchaser to withhold payments.

  1. The lien provided by this chapter covers:
    1. All the production of oil, gas and ore and minerals in solid form attributable to the interest subject to the lien;
    2. The proceeds of production attaching to the working interest as the working interest existed on the date labor was first performed or materials were first furnished;
    3. Any well;
    4. Oil derricks;
    5. Oil tanks;
    6. Any pipelines including rights-of-way;
    7. Any mine or quarry;
    8. All materials furnished for use with work done; and
    9. The whole of the land or leasehold (or, in the case of validly pooled or unitized lands, leases or interests, the lands, leases or interests so pooled or unitized) and including all other wells, buildings, property and appurtenances, including water rights, located on the land or leasehold (or pooled or unitized lands, leases or interests) where work was performed or materials furnished.
  2. Any lien claimed pursuant to this chapter covering oil, gas or ore and minerals in solid form or the proceeds of their sale is not effective against any purchaser of the oil, gas or ore and minerals in solid form until written notice of the claim is delivered by certified mail, return receipt requested, to the purchaser at his principal place of business. Notice shall state:
    1. The name of the claimant;
    2. His address;
    3. The amount of the lien; and
    4. The description of the interest on which the lien is claimed.
  3. The production of any mineral interest or working interest otherwise subject to a lien under this chapter is not to be encumbered until notice of the lien is delivered as provided in subsection (b) of this section to the holder of the interest. At the time notice is given any proceeds remaining unpaid or any proceeds yet to be paid on future sales of the mineral production shall be encumbered by the lien.
  4. A purchaser shall withhold payments for oil or gas runs or ore and minerals in solid form to the extent of the lien amount claimed until delivery of written notice the claim is settled or until otherwise ordered by a court of competent jurisdiction.

History. Laws 1955, ch. 101, § 7; W.S. 1957, § 29-31; Laws 1959, ch. 4, § 1; W.S. 1977, § 29-3-105 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Basic purpose of lien statutes, which are in derogation of the common law, is to create a new means of securing claims of particular classes of creditors and to prevent unjust enrichment arising from enhancement of property from which work and materials expended thereon would otherwise go without payment. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Mechanic's lien may arise by implication from the relations and dealings of the parties whose interests are involved. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Similarity to equitable lien. —

The statutorily created mechanic's lien is akin to an “equitable lien,” which has been defined as a right, not existing at law, to have specific property applied, in whole or in part, to the payment of a particular class of debts which may be created by express contract which shows an intention to charge some particular property with a debt obligation. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Effect of previous entry of judgment in favor of lienholder. —

Where the holder of a mechanic's lien as a statutory lien creditor against a corporate debtor obtained a choate lien upon the proceeds of the debtor's share of the proceeds of production in the hands of a judgment creditor with writ of execution upon service of the statutory notice, the previous entry of judgment in favor of the mechanic lienholder on the lien claim did not deprive the holder of the priority benefit of the lien. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Lien for labor and materials furnished assignee of lease extends to oil, not land. —

A lien for labor and material furnished under a contract with the assignee of an oil and gas lease, together with its priority, extends to the oil, and the proceeds thereof, as distinguished from the land or leasehold. Pheister v. Ogden Smelting & Ref. Mills, 364 P.2d 1078, 1961 Wyo. LEXIS 120 (Wyo. 1961).

But is superior to prior mortgage as to oil not in possession of mortgagee. —

Where the mortgagee made no effort of any kind whatever to take possession or control of oil produced on a leasehold, or the proceeds thereof, up to the time when plaintiff's lien for labor and material furnished under a contract with the assignee of an oil and gas lease became effective, the lien of the plaintiff must be held to be prior and superior to the claim of the mortgagee insofar as the oil and the proceeds thereof are concerned. The date of priority, however, must be held to relate back only to the time when the work and labor of the plaintiff was completed. Pheister v. Ogden Smelting & Ref. Mills, 364 P.2d 1078, 1961 Wyo. LEXIS 120 (Wyo. 1961).

Proper notice provided. —

Judgment was entered for a creditor on a trustee's claim under 11 U.S.C.S. § 544 to avoid the creditor's liens on oil and gas properties as unperfected because the trustee was bound by a judgment on the creditor's action to foreclose on the liens, which contained a finding that the creditor's liens were valid, and the creditor provided requisite notice of its asserted liens in the crude production proceeds under Wyo. Stat. Ann. § 29-3-105(b). Royal v. Sharkey Well Serv. (In re DCD, Inc.), 2006 Bankr. LEXIS 1455 (Bankr. D. Wyo. June 12, 2006).

Statutory oil and gas liens valid and perfected as of the dates liens were filed. —

Judgment was entered for a creditor on a trustee's preference claim under 11 U.S.C.S. § 547(b) because the creditor's statutory oil and gas liens were valid and perfected in the oil and gas properties as of the dates those liens were filed, and in the proceeds of production from the date notice was delivered to the purchaser of the debtor's crude oil production from the oil and gas properties subject to the creditor's lien statements under Wyo. Stat. Ann. § 29-3-105(b). The recording of the creditor's judgment on an action under Wyo. Stat. Ann. § 29-3-109(a) to foreclose the liens was irrelevant as to the date of the perfection of the liens and transfer date for purposes of 11 U.S.C.S. § 547. Royal v. Sharkey Well Serv. (In re DCD, Inc.), 2006 Bankr. LEXIS 1455 (Bankr. D. Wyo. June 12, 2006).

Relation back. —

Because a lien on production did not relate back to the time prior to the petition date under Wyoming law, a creditor’s post-petition actions did not fall within the scope and safeguards of the relation back exception; rather, these actions violated the automatic stay, as they would give rise to post-petition liens and cause interception of debtor receivables. Southland Royalty Co. LLC v. Halliburton Energy Servs. (In re Southland Royalty Co. LLC), 624 B.R. 331, 2021 Bankr. LEXIS 149 (Bankr. D. Del. 2021).

Resolution of a mechanic's lien claim did not make moot an oil and gas lien claim. —

Resolution of a mechanic's lien claim did not make moot an oil and gas lien claim because the two types of claims are very different, as shown by Wyo. Stat. Ann. § 29-3-103(a)(vi) and this section. KM Upstream, LLC v. Elkhorn Constr., Inc., 2012 WY 79, 278 P.3d 711, 2012 Wyo. LEXIS 84 (Wyo. 2012).

Cited in

Burg v. Ruby Drilling Co., 783 P.2d 144, 1989 Wyo. LEXIS 230 (Wyo. 1989).

Am. Jur. 2d, ALR and C.J.S. references. —

Rights and liabilities with respect to natural gas reduced to possession and subsequently stored in natural reservoir, 94 ALR2d 543.

Assertion of statutory mechanic's or materialman's lien against oil and gas produced or against proceeds attributable to oil and gas sold, 59 ALR3d 278.

Oil and gas farmout agreements, 65 ALR5th 211.

§ 29-3-106. Lien statement to be filed; $750 minimum; place and time of filing.

  1. To perfect the lien provided by this chapter, a lien statement shall be filed with the county clerk and notice by certified mail shall be given by the lien claimant.
  2. The lien statement may be filed and the lien shall attach and be enforced if any sum exceeding seven hundred fifty dollars ($750.00) for materials furnished or work performed according to this chapter is owing. The lien claimant may file a lien statement in the office of the county clerk in any county where any part of the land, leasehold, mine, quarry, pipeline or other property to which a lien may attach under this chapter is situated within one hundred eighty (180) days:
    1. After the last day materials were delivered or work was performed under contract;
    2. From the date the work was substantially completed as determined by the facts in each case; or
    3. With respect to an employee or subcontractor, after the last day he performed work at the direction of his employer or contractor.

History. Laws 1919, ch. 128, § 4; C.S. 1920, § 4833; R.S. 1931, § 66-607; C.S. 1945, § 55-404; Laws 1955, ch. 101, § 3; W.S. 1957, § 29-34; W.S. 1977, § 29-3-108 ; Laws 1981, Sp. Sess., ch. 17, § 2; 1983, ch. 74, § 1; 2010, ch. 38, § 1.

The 2010 amendment, effective July 1, 2010, substituted “lien claimant” for “county clerk” at the end of (a).

Applied in

Oxley v. Mine & Smelter Supply Co., 439 P.2d 661, 1968 Wyo. LEXIS 164 (Wyo. 1968).

Cited in

Craig v. Higgins, 31 Wyo. 166, 224 P. 668, 1924 Wyo. LEXIS 15 (1924).

§ 29-3-107. Property not to be sold or removed after perfected lien attaches without lienholder's consent; lienholder's rights upon violation.

  1. Property subject to a perfected lien shall not be sold or removed from the premises where it is located without the written consent of the holder of the lien and as may be appropriate by:
    1. The owner of the land;
    2. The owner of any associated oil, gas or mineral leasehold interest;
    3. The owner of any oil, gas or water pipeline;
    4. Any contractor or subcontractor;
    5. The purchaser, trustee, receiver or agent of any owner;
    6. Any lessor or lessee; or
    7. Any agent of any contractor, subcontractor or purchaser.
  2. If a violation of this section occurs, the lienholder is entitled to possession of the property against which a perfected lien has attached wherever located and is entitled to have the property sold for payment of the debt whether the debt is due or not.

History. Laws 1919, ch. 128, § 6; C.S. 1920, § 4835; R.S. 1931, § 66-609; C.S. 1945, § 55-406; W.S. 1957, § 29-35; W.S. 1977, § 29-3-109 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Section does not deprive owner of right to possession prior to foreclosure. Chittim v. Armco Steel Corp., 407 P.2d 1015, 1965 Wyo. LEXIS 170 (Wyo. 1965).

§ 29-3-108. Fraudulent violation of section 29-3-107; penalty.

If any person removes any property covered by the lien created by this chapter from its location when the lien is filed and recorded without the written consent of the holder of the lien and with intent to defraud the lienholder, either originally or by transfer, the person removing or causing the property to be removed is guilty of a misdemeanor. On conviction he shall be punished by a fine of not more than seven hundred fifty dollars ($750.00).

History. Laws 1919, ch. 128, § 7; C.S. 1920, § 4836; R.S. 1931, § 66-610; C.S. 1945, § 55-407; W.S. 1957, § 29-36; W.S. 1977, § 29-3-110 ; Laws 1981, Sp. Sess., ch. 17, § 2.

§ 29-3-109. Limitation of actions and duration of liens; procedure when property subject to lien removed to another county.

  1. Every person holding a lien created by this chapter may proceed to obtain a judgment for the amount claimed by civil action commenced on the account within one hundred eighty (180) days after filing of the lien statement required by W.S. 29-3-106 . The lien shall continue until the case is finally determined.
  2. If any person removes any property subject to a lien to a county other than the one in which the lien is filed, the lien claimant may within thirty (30) days thereafter file with the county clerk of the county to which it has been removed an itemized inventory of the property removed. The inventory shall show the amount due and unpaid on the lien. The inventory shall be recorded in the lien records of that county. The filing shall operate as a notice of the continuing existence of the lien. The lien shall attach and extend to the land or leasehold and other premises, properties and appurtenances to which the property removed is attached.

History. Laws 1919, ch. 128, § 5; C.S. 1920, § 4834; R.S. 1931, § 66-608; C.S. 1945, § 55-405; Laws 1951, ch. 35, § 3; W.S. 1957, § 29-37; W.S. 1977, § 29-3-111 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2004, ch. 130, § 1.

Cross references. —

See also § 29-2-109 and cross references thereunder.

The 2004 amendment, in (a), substituted “lien statement” for “notice” and “29-3-106” for “29-3-108.”

Laws 2004, ch. 130, § 4, makes the act effective immediately upon completion of all acts necessary for a bill to become law as provided by art. 4, § 8, Wyo. Const. Approved March 19, 2004.

Conflicting legislation. —

Laws 2004, ch. 130, § 3, provides: “Any other act adopted by the Wyoming legislature during the same session in which this act is adopted shall be given precedence and shall prevail over the amendments in this act to the extent that such acts are in conflict with this act.”

Basic purpose of lien statutes, which are in derogation of the common law, is to create a new means of securing claims of particular classes of creditors and to prevent unjust enrichment arising from enhancement of property from which work and materials expended thereon would otherwise go without payment. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Mechanic's lien may arise by implication from the relations and dealings of the parties whose interests are involved. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Similarity to equitable lien. —

The statutorily created mechanic's lien is akin to an “equitable lien,” which has been defined as a right, not existing at law, to have specific property applied, in whole or in part, to the payment of a particular class of debts which may be created by express contract which shows an intention to charge some particular property with a debt obligation. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Choate lien. —

The mechanic's lien of a materialman is a “choate” lien following service of notice. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

Effect of previous entry of judgment in favor of lienholder. —

Where the holder of a mechanic's lien as a statutory lien creditor against a corporate debtor obtained a choate lien upon the proceeds of the debtor's share of the proceeds of production in the hands of a judgment creditor with writ of execution upon service of the statutory notice, the previous entry of judgment in favor of the mechanic's lienholder on the lien claim did not deprive the holder of the priority benefit of the lien. Permian Corp. v. Armco Steel Corp., 508 F.2d 68, 1974 U.S. App. LEXIS 5581 (10th Cir. Wyo. 1974).

§ 29-3-110. Limitation upon owner's liability and rights.

Nothing in this chapter shall be construed to fix a greater liability against the owner of the land or leasehold (or pooled or unitized lands, leases or interests, as the case may be) than the price or sum stipulated by the owner to be paid for the materials or services furnished or labor performed. The owner shall not have the right to offset obligations of the contractor unless these obligations arise out of the original contract.

History. Laws 1919, ch. 128, § 9; C.S. 1920, § 4838; R.S. 1931, § 66-612; C.S. 1945, § 55-409; Laws 1955, ch. 101, § 4; W.S. 1957, § 29-39; W.S. 1977, § 29-3-113; Laws 1981, Sp. Sess., ch. 17, § 2; 2004, ch. 130, § 1.

The 2004 amendment substituted “chapter” for “act.”

Laws 2004, ch. 130, § 4, makes the act effective immediately upon completion of all acts necessary for a bill to become law as provided by art. 4, § 8, Wyo. Const. Approved March 19, 2004.

Conflicting legislation. —

Laws 2004, ch. 130, § 3, provides: “Any other act adopted by the Wyoming legislature during the same session in which this act is adopted shall be given precedence and shall prevail over the amendments in this act to the extent that such acts are in conflict with this act.”

Severability. —

Section 10, ch. 128, Laws 1919, provided that if any of the provisions thereof should be held invalid or unenforceable the remainder of the act should not be affected thereby.

Property held subject to materialmen's liens after principal contractor paid in full. —

The oil and gas leasehold estate and well of the owner may be subject to materialmen's liens for amounts owing from the principal contractor to materialmen when the owner paid the principal contractor in full, pursuant to the drilling contract, after the well was completed prior to receiving notice from the materialmen that they had not been paid by the principal contractor. Arnold v. American Pipe & Supply Co., 413 P.2d 874, 1966 Wyo. LEXIS 143 (Wyo. 1966).

Subcontractor has no lien against leasehold unless contractor has an agreement with owner that the owner will pay for the services asserted in the lien. Adobe Oil & Gas Corp. v. Getter Trucking, 676 P.2d 560, 1984 Wyo. LEXIS 251 (Wyo. 1984).

Cited in

National Supply Company-Midwest v. Weaver, 35 Wyo. 224, 248 P. 353, 1926 Wyo. LEXIS 15 (1926); Burg v. Ruby Drilling Co., 783 P.2d 144, 1989 Wyo. LEXIS 230 (Wyo. 1989).

§ 29-3-111. Claim against contractor submitted to owner; reduction of subsequent payments to contractor by owner; duty of owner to notify contractor and of contractor to dispute or adjust claim.

  1. Every person performing any work or furnishing any material, as specified in this chapter, under contract whose demand to be reimbursed for the work done or material furnished has not been paid shall serve the owner by certified mail return receipt requested, with an account signed before a notarial officer of the amount and value of the work performed or the material furnished remaining unpaid. Thereafter the owner or his agent shall retain out of any subsequent payments to the contractors the value of the work performed or material furnished for the person making the claim.
  2. When notice is served on the owner according to subsection (a) of this section he shall immediately furnish the contractor with a copy of the notice.
  3. Within ten (10) days of receipt of the notice required by this section the contractor shall give the owner affirmative written notice of:
    1. His intent to dispute the claim; or
    2. His intent the claim should be settled as filed.
  4. If within ten (10) days after receiving notice the contractor takes no action he shall be presumed to have agreed to the validity of the claim. The owner is then authorized to withhold enough of all subsequent payments to be made to the contractor to pay all claims as they come due.

History. C.L. 1876, ch. 77, Part V, §§ 2, 3; R.S. 1887, §§ 1494, 1495; R.S. 1899, §§ 2876, 2877; C.S. 1910, §§ 3786, 3787; C.S. 1920, §§ 4846, 4847; R.S. 1931, §§ 66-619, 66-620; C.S. 1945, §§ 55-311, 55-312; W.S. 1957, §§ 29-50, 29-51; W.S. 1977,§§ 29-3-221, 29-3-222; Laws 1981, Sp. Sess., ch. 17, § 2; 2008, ch. 20, § 2.

The 2008 amendment, effective July 1, 2008, substituted “notarial officer” for “notary public” in the first sentence of (a).

Property held subject to materialmen's liens after principal contractor paid in full. —

The oil and gas leasehold estate and well of the owner may be subject to materialmen's liens for amounts owing from the principal contractor to materialmen when the owner paid the principal contractor in full, pursuant to the drilling contract, after the well was completed prior to receiving notice from the materialmen that they had not been paid by the principal contractor. Arnold v. American Pipe & Supply Co., 413 P.2d 874, 1966 Wyo. LEXIS 143 (Wyo. 1966).

Cited in

Adobe Oil & Gas Corp. v. Getter Trucking, Inc., 676 P.2d 560, 1984 Wyo. LEXIS 251 (Wyo. 1984).

Chapter 4 Labor and Materials on Ditches, Canals and Reservoirs

Cross references. —

As to lien upon reservoirs, irrigation systems and ditches, see § 36-7-326 .

As to authority of board of directors of water conservancy districts to discharge and create liens in connection with use and distribution of water, see § 41-3-749 .

As to lien for work done, etc., in connection with jointly owned ditches, see § 41-5-103 .

As to liens for labor and materials in connection with irrigation works generally, see §§ 41-5-201 to 41-5-203 .

As to liens on annual assessment on the use of water, see § 41-7-408 .

§ 29-4-101. Persons entitled to lien; extent thereof.

  1. Any person who performs any work or furnishes any materials for the construction or improvement of any ditch, canal or reservoir under contract with the owner or his contractor or subcontractor, on complying with W.S. 29-2-101 through 29-2-109 , is entitled to a lien for work done or material furnished upon the ditch, canal or reservoir. The lien covers:
    1. The right-of-way for the ditch, canal or reservoir;
    2. The pertinent water permits and water rights; and
    3. The reclaimed lands for which the ditch, canal or reservoir was constructed.

History. Laws 1917, ch. 54, § 1; C.S. 1920, § 4860; R.S. 1931, § 66-502; C.S. 1945, § 55-225; W.S. 1957, § 29-73; W.S. 1977, § 29-4-101 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

Company that constructed ditch and obtained water rights in connection with development of land, under Carey Act, has an interest in such ditch, water rights and other appurtenances to which a lien may attach for work and material furnished in constructing the ditch. Lakeview Canal Co. v. R. Hardesty Mfg. Co., 31 Wyo. 182, 224 P. 853, 1924 Wyo. LEXIS 20 (Wyo. 1924).

§ 29-4-102. Filing of lien statement; enforcement.

Any person entitled may file a lien statement as provided by W.S. 29-1-103 through 29-1-314 and 29-2-101 through 29-2-113 and may enforce his lien in the same manner.

History. Laws 1917, ch. 54, § 2; C.S. 1920, § 4861; R.S. 1931, § 66-503; C.S. 1945, § 55-226; W.S. 1957, § 29-74; W.S. 1977, § 29-4-102 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2010, ch. 92, § 2.

The 2010 amendment, effective July 1, 2011, substituted “W.S. 29-1-103 through 29-1-314 ” for “W.S. 29-1-101 through 29-1-308 ” and “through 29-2-113 ” for “through 29-2-109 .”

Chapter 5 Owners and Operators of Harvesting Machines

Am. Jur. 2d, ALR and C.J.S. references. —

3 Am. Jur. 2d Agriculture §§ 8 to 18.

§ 29-5-101. Definitions.

  1. As used in this chapter:
    1. “Crops” means any agricultural products grown or processed in this state;
    2. “Elevators” means facilities leasing space for storage of crops;
    3. “Harvesting” means cubing, baling, threshing, combining, swathing, chopping, digging, picking or shelling crops.

History. Laws 1925, ch. 16, § 8; R.S. 1931, § 66-808; C.S. 1945, § 34-1508; W.S. 1957, § 29-92; W.S. 1977, § 29-5-101 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

§ 29-5-102. Persons entitled to lien; extent thereof.

All persons owning or operating harvesting machines are entitled to a lien on the crops harvested by them for the work performed in harvesting the crops.

History. Laws 1925, ch. 16, § 1; 1927, ch. 77, § 1; R.S. 1931, § 66-801; Laws 1933, ch. 11, § 1; C.S. 1945, § 34-1501; W.S. 1957, § 29-93; W.S. 1977, § 29-5-102 ; Laws 1981, Sp. Sess., ch. 17, § 2.

§ 29-5-103. Lien statement to be filed; contents; mistake in description not fatal; notice to purchaser or owner.

  1. Every person proceeding under this chapter shall file a lien statement sworn before a notarial officer setting forth the amount claimed to be due him with the county clerk of the county in which the crops were grown, within thirty (30) days after:
    1. The last work performed under contract in the harvesting of the crops; or
    2. The work was substantially completed.
  2. In addition to the requirements of W.S. 29-1-312(a) this statement shall contain:
    1. A description of the legal subdivision of land where the crops are stored; and
    2. If the crops are stored in an elevator, the location of the elevator.
  3. Any error or mistake in the statement describing the crops or the property on which they were raised shall not invalidate the lien.
  4. If the crops are being hauled from the machine direct to the elevator or to any purchaser any person desiring to claim a lien by proceeding under this chapter shall serve written notice on the purchaser or the owner of the crops that he may claim a lien on the crops for his work performed.

History. Laws 1925, ch. 16, § 2; 1927, ch. 77, § 2; R.S. 1931, § 66-802; C.S. 1945, § 34-1502; W.S. 1957, § 29-94; W.S. 1977, § 29-5-103 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2008, ch. 20, § 2; 2010, ch. 92, § 2.

Cross references. —

See also § 29-2-109 and cross references thereunder. As to duration of lien, see § 29-5-105 .

The 2008 amendment, effective July 1, 2008, substituted “notarial officer” for “notary public” in the introductory language of (a).

The 2010 amendment, effective July 1, 2011, substituted “W.S. 29-1-312(a)” for “W.S. 29-1-301(a)” in the introductory language of (b).

§ 29-5-104. Priority of lien.

The lien for work performed as specified in W.S. 29-5-102 has precedence over any mortgage or encumbrance except those created by W.S. 29-8-102 relating to liens for the production of farm products under contracts executed, entered into, renewed or substantively amended after July 1, 2001.

History. Laws 1925, ch. 16, § 4; R.S. 1931, § 66-804; C.S. 1945, § 34-1504; W.S. 1957, § 29-96; W.S. 1977, § 29-5-105 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2001, ch. 126, § 2.

§ 29-5-105. Limitation of actions; duration of lien.

Actions for the foreclosure of the lien provided by this chapter shall be commenced within sixty (60) days from the filing of the lien statement. No lien continues to exist by virtue of this chapter for more than sixty (60) days after the lien is filed unless within that time a civil action is instituted to obtain a judgment. When any action commences within the sixty (60) days, the lien continues until the suit is finally determined and satisfied.

History. Laws 1925, ch. 16, § 5; R.S. 1931, § 66-805; C.S. 1945, § 34-1505; W.S. 1957, § 29-97; W.S. 1977, § 29-5-106 ; Laws 1981, Sp. Sess., ch. 17, § 2.

Cross references. —

See also § 29-2-109 and notes thereunder. As to filing of lien and notice to purchasers, see § 29-5-103 .

§ 29-5-106. Removal of encumbered property without lienholder's consent; penalty.

If any person removes any property covered by the lien created by this chapter from the place where the property is located when the lien statement is filed without the written consent of the holder of the lien, either originally or by transfer, the person causing the property to be removed is guilty of a misdemeanor. On conviction he may be fined not more than seven hundred fifty dollars ($750.00).

History. Laws 1925, ch. 16, § 10; R.S. 1931, § 66-810; C.S. 1945, § 34-1510; W.S. 1957, § 29-101; W.S. 1977, § 29-5-110; Laws 1981, Sp. Sess., ch. 17, § 2.

Chapter 6 Federal Lien Registration

Cross references. —

For authority of county clerk relative to filing or recording liens or claims in favor of the United States, see § 18-3-402 .

Law reviews. —

See note, “Federal Tax Liens in Mortgage Foreclosures,” 13 Wyo. L.J. 146 (1959).

Am. Jur. 2d, ALR and C.J.S. references. —

72 Am. Jur. 2d State and Local Taxation §§ 798-805.

Article 1. Federal Tax Lien Registration

§§ 29-6-101 through 29-6-107. [Repealed.]

Repealed by Laws 1988, ch. 41, § 2.

Cross references. —

As to federal lien registration, see article 2 of this chapter.

Editor's notes. —

These sections, which were derived from Laws 1929, ch. 38, §§ 1 through 7, comprised the Uniform Federal Tax Lien Registration Act.

Article 2. Federal Lien Registration

Federal tax liens. —

Pursuant to former § 34.1-9-102(b) (now see § 34.1-9-109(c)), the Uniform Commercial Code does not apply to statutory liens like the one the Internal Revenue Service obtains under 26 USCS § 6321; perfection of a federal tax lien is instead governed by the Uniform Federal Lien Registration Act found in this article. Straight v. First Interstate Bank of Commerce (In re Straight), 207 B.R. 217, 1997 Bankr. LEXIS 454 (B.A.P. 10th Cir. Wyo. 1997).

Law reviews. —

See “Precautions of the Title Examiner in Relation to Federal Tax Liens,” 6 Wyo. L.J. 195.

Am. Jur. 2d, ALR and C.J.S. references. —

Sufficiency of designation of taxpayer in recorded notice of federal tax lien, 3 ALR3d 633.

Sufficiency of notice of sale of property, under 26 USCS § 6335, seized for failure to pay federal taxes, 26 ALR Fed 381.

§ 29-6-201. Short title.

This act [§§ 29-6-201 through 29-6-208 ] shall be known and may be cited as the “Uniform Federal Lien Registration Act”.

History. Laws 1988, ch. 41, § 1.

Applied in

Straight v. First Interstate Bank of Commerce, 200 B.R. 923, 1996 Bankr. LEXIS 782 (Bankr. D. Wyo. 1996).

§ 29-6-202. Application and construction of provisions.

This act [§§ 29-6-201 through 29-6-208 ] shall be applied and construed to effectuate its general purpose to make uniform the laws of those states which enact it.

History. Laws 1988, ch. 41, § 1.

§ 29-6-203. Applicability.

This act [§§ 29-6-201 through 29-6-208 ] applies only to federal tax liens and to other federal liens, notices of which under any act of congress or any regulation adopted pursuant thereto are required or permitted to be filed in the same manner as notices of federal tax liens.

History. Laws 1988, ch. 41, § 1.

§ 29-6-204. Federal liens; place of filing.

  1. Notices of liens, certificates and other notices affecting federal tax liens or other federal liens shall be filed in accordance with this act [§§ 29-6-201 through 29-6-208 ].
  2. Notices of liens upon real property for obligations payable to the United States and certificates and notices affecting the liens shall be filed in the office of the county clerk of the county in which the real property subject to the liens is situated.
  3. Notices of federal liens upon personal property, whether tangible or intangible, for obligations payable to the United States and certificates and notices affecting the liens shall be filed as follows:
    1. If the person against whose interest the lien applies is a corporation or a partnership whose principal executive office is in this state, as these entities are defined in the internal revenue laws of the United States, in the office of the secretary of state;
    2. If the person against whose interest the lien applies is a trust that is not covered by paragraph (i) of this subsection, in the office of the secretary of state;
    3. If the person against whose interest the lien applies is the estate of a decedent, in the office of the secretary of state;
    4. In all other cases, in the office of the county clerk of the county where the person against whose interest the lien applies resides at the time of filing of the notice of lien.

History. Laws 1988, ch. 41, § 1.

Bankruptcy proceedings. —

Where the internal revenue service properly filed its notice of federal tax lien in the office of the county clerk in the county where bankruptcy debtors resided, the tax lien could not be avoided in bankruptcy as an unperfected lien. Straight v. First Interstate Bank of Commerce (In re Straight), 200 B.R. 923, 1996 Bankr. LEXIS 782 (Bankr. D. Wyo. 1996), aff'd, 207 B.R. 217, 1997 Bankr. LEXIS 454 (B.A.P. 10th Cir. Wyo. 1997).

Federal tax liens. —

To perfect a lien in personal property owned by anyone other than a corporation, partnership, trust or estate of a decedent, the Internal Revenue Service need only file notice of the lien with the county clerk in the county of the taxpayer's residence pursuant to paragraph (c)(iv). Straight v. First Interstate Bank of Commerce (In re Straight), 207 B.R. 217, 1997 Bankr. LEXIS 454 (B.A.P. 10th Cir. Wyo. 1997).

§ 29-6-205. Certification of notices and certificates.

Certification of notices of liens, certificates or other notices affecting federal liens by the secretary of the treasury of the United States or his delegate, or by any official or entity of the United States responsible for filing or certifying of notice of any other lien, entitles them to be filed and no other attestation, certification or acknowledgement is necessary.

History. Laws 1988, ch. 41, § 1.

§ 29-6-206. Duties of filing officer.

  1. If a notice of federal lien, a refiling of a notice of federal lien or a notice of revocation of any certificate described in subsection (b) of this section is presented to a filing officer who is:
    1. The secretary of state, he shall cause the notice to be marked, held and indexed in accordance with the provisions of W.S. 34.1-9-519 of the Uniform Commercial Code as if the notice were a financing statement within the meaning of that code; or
    2. Any other officer described in W.S. 29-6-204 , he shall endorse thereon his identification and the date and time of receipt and immediately file it alphabetically or enter it in an alphabetical index showing the name and address of the person named in the notice, the date and time of receipt, the title and address of the official or entity certifying the lien and the total amount appearing on the notice of lien.
  2. If a certificate of release, nonattachment, discharge or subordination of any lien is presented to the secretary of state for filing he shall:
    1. Cause a certificate of release or nonattachment to be marked, held and indexed as if the certificate were a termination statement within the meaning of the Uniform Commercial Code and maintain a permanent record of the notice of the lien in the file or on microfilm or by other photographic means; and
    2. Cause a certificate of discharge or subordination to be marked, held and indexed as if the certificate were a release of collateral within the meaning of the Uniform Commercial Code.
  3. If a refiled notice of federal lien referred to in subsection (a) of this section or any of the certificates or notices referred to in subsection (b) of this section is presented for filing to any other filing officer specified in W.S. 29-6-204 , he shall permanently attach the refiled notice or the certificate to the original notice of lien and enter the refiled notice or the certificate with the date of filing in any alphabetical lien index on the line where the original notice of lien is entered.
  4. Upon request of any person, the filing officer shall issue his certificate showing whether there is on file, on the date and hour stated therein, any notice of lien or certificate or notice affecting any lien filed under this act [§§ 29-6-201 through 29-6-208 ] or under W.S. 29-6-101 through 29-6-107 [repealed] as those sections existed prior to the enactment of this act, naming a particular person, and if a notice or certificate is on file, giving the date and hour of filing of each notice or certificate.

History. Laws 1988, ch. 41, § 1; 2004, ch. 130, § 1.

The 2004 amendment, in (a)(i), substituted “W.S. 34.1-9-519” for “W.S. 34.1-9-403(d)”; and, in (c), substituted “W.S. 29-6-204 ” for “W.S. 26-9-204 .”

Laws 2004, ch. 130, § 4, makes the act effective immediately upon completion of all acts necessary for a bill to become law as provided by art. 4, § 8, Wyo. Const. Approved March 19, 2004.

Editor's notes. —

Sections 29-6-101 through 29-6-107, referred to in subsection (d), were repealed in 1988.

Conflicting legislation. —

Laws 2004, ch. 130, § 3, provides: “Any other act adopted by the Wyoming legislature during the same session in which this act is adopted shall be given precedence and shall prevail over the amendments in this act to the extent that such acts are in conflict with this act.”

Clerk authority.—

District court properly dismissed a property owner’s declaratory judgment action seeking to require a county clerk to remove a notice of federal tax lien (NFTL) from the property record where the clerk had a mandatory obligation under Wyo. Stat. Ann. §§ 29-6-206(a)(ii) and 18-3-402(a)(xii) to file the NFTL, and nothing in her general statutory authority or her authority under the Uniform Federal Lien Registration Act, Wyo. Stat. Ann. § 29-6-201 et seq. (2017), permitted her to independently question the underlying validity of the NFTL, remove it from the property record, or record a document declaring it invalid. Tuttle v. Lee, 2018 WY 104, 425 P.3d 998, 2018 Wyo. LEXIS 108 (Wyo. 2018).

§ 29-6-207. Fees.

Fees for filings, lien searches, certifications and copying under this act [§§ 29-6-201 through 29-6-208 ] shall be the same as the fees prescribed for financing statements under W.S. 34.1-9-409 [§ 34.1-9-525].

History. Laws 1988, ch. 41, § 1.

Editor's notes. —

Following the 2001 revision of article 9 of the Uniform Commercial Code, the apparent reference is § 34.1-9-525.

§ 29-6-208. Prior filings of notices and certificates.

Filing officers with whom notices of federal tax liens, certificates and notices affecting those liens have been filed on or before July 1, 1988, shall, after that date, continue to maintain in a file, on microfilm or by other photographic means, copies of all federal tax lien notices filed prior to July 1, 1988, notices and certificates filed in numerical order of receipt. If a notice of lien was filed on or before July 1, 1988, any certificate or notice affecting the lien shall be filed in the same office.

History. Laws 1988, ch. 41, § 1.

Chapter 7 Personal Property

Cross references. —

As to perfecting security interests in general, see § 34.1-9-308 et seq.

Am. Jur. 2d, ALR and C.J.S. references. —

Bailee's lien for work on goods as extending to other goods of the bailor in his possession, 25 ALR2d 1037.

Priority as between lien for repairs and the like, and right of seller under conditional sales contract, 36 ALR2d 198.

Priority as between artisan's lien and chattel mortgage, 36 ALR2d 229.

Garageman's lien: modern view as to validity of statute permitting sale of vehicle without hearing, 64 ALR3d 814.

Right of mortgagee and/or lienor to compensation when property subject to mortgage and/or lien is taken by federal governmental forfeiture based on criminal acts of owner, 136 ALR Fed 593.

Article 1. In General

§ 29-7-101. Persons entitled to lien; exception.

  1. Any person is entitled to a lien on any goods, chattels or animals for his reasonable charges for work or services performed or feed provided when he:
    1. Makes, alters, repairs, bestows work upon, transports, stores or keeps the same; or
    2. Feeds, herds, pastures or cares for any domestic or wild animal lawfully held in captivity. Any person creating a lien under this paragraph shall file the lien in the office of the secretary of state.
  2. W.S. 29-7-101 through 29-7-106 shall not apply where a lien is provided by W.S. 29-7-301 and 34.1-7-209. A person engaging in self-storage operations whereby members of the public rent space from the person to store goods and chattels and retain control over access to the goods and chattels is not a warehouseman under W.S. 34.1-7-102(a)(xiii) and is entitled to a lien under this section. A towing and recovery service as defined in W.S. 31-13-101(a)(xiv) is not a warehouse under W.S. 34.1-7-102(a)(xiii) and is entitled to a lien under this section.

History. Laws 1967, ch. 89, § 1; W.S. 1977, § 29-7-101 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2004, ch. 24, § 1; 2021, ch. 105, § 1; ch. 149, § 1.

The 2004 amendment, effective July 1, 2004, in (a)(ii), added the last sentence.

The 2021 amendments. —

The first 2021 amendment, by ch. 105, § 1, effective July 1, 2021, added the last sentence of (b).

The second 2021 amendment, by ch. 149, § 1, effective July 1, 2021, in the first sentence of (b), deleted "34.1-7-209 and" preceding "29 7 301," added "and 34.1-7-209" and substituted "34.1-7-102(a)(xiii)" for "34.1-7-102(a)(viii)" in the second sentence.

This section is set out as reconciled by the Wyoming legislative service office.

Right to lien inconsistent with conversion. —

Verdict finding a rancher liable for conversion of a beefalo herd was inconsistent with a verdict entitling the rancher to a lien against the same property, under Wyo. Stat. Ann. § 29-7-101 et seq., for feeding the herd because the existence of the lien depended on the rancher's rightful possession of the subject property. McTiernan v. Jellis, 2013 WY 151, 316 P.3d 1153, 2013 Wyo. LEXIS 157 (Wyo. 2013).

Legislative history of this chapter. —

See Minnehoma Fin. Co. v. Pauli, 565 P.2d 835, 1977 Wyo. LEXIS 308 (Wyo. 1977).

Lien is statutory. —

There was no common-law lien for storage and, therefore, such a lien can only be acquired by statute. Minnehoma Fin. Co. v. Pauli, 565 P.2d 835, 1977 Wyo. LEXIS 308 (Wyo. 1977).

Owner may not impose lien. —

Under the plain and ordinary language contained in subsection (a) of this section and § 29-7-106(a), only a third-party creditor, and not the owner, may impose a lien upon the secured property. Coones v. FDIC, 894 P.2d 613, 1995 Wyo. LEXIS 71 (Wyo. 1995).

Under this section, implied request to store may give rise to valid storage lien, and such an implied request arises when the owner of goods abandons such goods on the property of another. Minnehoma Fin. Co. v. Pauli, 565 P.2d 835, 1977 Wyo. LEXIS 308 (Wyo. 1977).

Mobile home park operator is entitled to storage lien on mobile home which is abandoned on his property by a tenant. Minnehoma Fin. Co. v. Pauli, 565 P.2d 835, 1977 Wyo. LEXIS 308 (Wyo. 1977).

Landlord not entitled to lien for past due rent. —

Sections 29-7-101 through 29-7-106 do not entitle a landlord to a lien for past rent due on the personal property of its tenant, or that of a third party, located on the rented premises. Sheridan Commercial Park v. Briggs, 848 P.2d 811, 1993 Wyo. LEXIS 44 (Wyo. 1993).

Quoted in

Rocky Mt. Turbines, Inc. v. 660 Syndicate, Inc., 623 P.2d 758, 1981 Wyo. LEXIS 289 (Wyo. 1981).

Am. Jur. 2d, ALR and C.J.S. references. —

Liability to pay for allegedly unauthorized repairs to motor vehicle, 5 ALR4th 311.

§ 29-7-102. Right of possession by lien claimant; termination thereof; removal of property without lienholder's consent; penalty therefor; filing of lien statement in lieu of possession.

  1. A lien claimant may retain possession of the property to which the lien pertains until paid for the labor, services, materials and feed which entitle the lien claimant to assert the lien. However, the right of possession terminates six (6) months after the date upon which the charges become due and payable unless the lien claimant has commenced proceedings to foreclose the lien as provided by W.S. 29-7-101 through 29-7-106 .
  2. If any person causes to be removed from the possession of a lien claimant any property or part thereof which is subject to the lien created by W.S. 29-7-101 through 29-7-106 from the place where the property was located when the lien is perfected, without the written consent of the owner and the holder of the lien or his agent, either originally or by transfer, the person so removing the property affected by the lien is guilty of a misdemeanor. On conviction he may be punished by a fine of not more than seven hundred fifty dollars ($750.00).
  3. If a lien claimant desires to continue a lien without retaining possession, he may before voluntarily releasing possession file a lien statement in the office of the county clerk of the county where the property is located, or in the case of a feeder’s lien under paragraph (a)(ii) of this section, in the office of the secretary of state.
  4. If possession is terminated without the lien claimant’s consent, he may perfect the lien by filing a lien statement on or before thirty (30) days after possession is terminated.
  5. For a vehicle subject to a lien under this title:
    1. Within thirty (30) days from the date payment is due, the lien claimant shall send by certified mail, return receipt requested, to their last known address a notice of the intent to file, enforce and foreclose a lien to all persons known to claim an interest in the vehicle. The notice shall include:
      1. The information required under W.S. 29-7-105(b);
      2. The information required under W.S. 29-1-312(b); and
      3. The make, year, model, license plate number and state indicator if available, and vehicle identification number.
    2. The duration of collectable storage fees shall not exceed one hundred eighty (180) days from the date service was completed unless notice of intent to file a lien was sent pursuant to this subsection and action to enforce and foreclose the lien has commenced;
    3. “Vehicle” means as defined in W.S. 31-13-101(a)(ix).

History. Laws 1967, ch. 89, § 2; W.S. 1977, § 29-7-102 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2004, ch. 24, § 1; 2021, ch. 105, § 1.

The 2004 amendment, effective July 1, 2004, in (c), added “or in the case of a feeder's lien under paragraph (a)(ii) of this section, in the office of the secretary of state” at the end.

The 2021 amendment, effective July 1, 2021, added (e).

Quoted in

Rocky Mt. Turbines, Inc. v. 660 Syndicate, Inc., 623 P.2d 758, 1981 Wyo. LEXIS 289 (Wyo. 1981); Bosler v. Shuck, 714 P.2d 1231, 1986 Wyo. LEXIS 492 (Wyo. 1986).

§ 29-7-103. Lien statement; additional contents; county clerk to note lien on certificate of title.

  1. A lien statement under W.S. 29-7-101 through 29-7-106 shall provide in addition to the requirements of W.S. 29-1-312(b) whether the lien claimant was in possession of the property at the time the lien statement was filed or the owner consented to the filing of the lien. Notwithstanding W.S. 29-1-312(a), a feeder’s lien created pursuant to W.S. 29-7-101 (a)(ii) shall be filed in the office of the secretary of state together with any applicable filing fees.
  2. A lien statement relating to a motor vehicle or other property, title to which is evidenced by a certificate of title, shall not be valid as to the motor vehicle or property unless the county clerk concurrently with the filing of the lien statement places on the certificate of title an appropriate notation showing the date, the amount of the lien and the name of the lien claimant. Each notation under this subsection after the first shall be accompanied by a fee of one dollar ($1.00) paid to the county clerk. If the county clerk issues the certificate of title, he shall immediately endorse the same encumbrance data on the certificate copy on file in his office. If the certificate is issued in some other county or state the county clerk shall promptly transmit to the state or county officer who issued the certificate of title the same encumbrance data. The other county officer shall promptly place the data on the certificate copy on file in his office.

History. Laws 1967, ch. 89, § 3; W.S. 1977, § 29-7-103 ; Laws 1981, Sp. Sess., ch. 17, § 2; 1993, ch. 192, § 1; 2004, ch. 24, § 1; ch. 130, § 1; 2010, ch. 92, § 2.

The 2004 amendments. —

The first 2004 amendment, by ch. 24, § 1, effective July 1, 2004, in (a), substituted “W.S. 29-1-301(b)” for “W.S. 29-1-301(a),” and added the last sentence.

The second 2004 amendment, by ch. 130, § 1, in (a) substituted “29-1-301(b)” for “29-1-301(a),”

Laws 2004, ch. 130, § 4, makes the act effective immediately upon completion of all acts necessary for a bill to become law as provided by art. 4, § 8, Wyo. Const. Approved March 19, 2004.

The 2010 amendment, effective July 1, 2011, in (a), substituted “W.S. 29-1-312(b)” for “W.S. 29-1-301(b)” and “W.S. 29-1-312(a)” for “W.S. 29-1-301(a).”

Editor's notes. —

See the conflicting legislation note below. This section has been set out incorporating changes made by both 2004 acts.

Conflicting legislation. —

Laws 2004, ch. 130, § 3, provides: “Any other act adopted by the Wyoming legislature during the same session in which this act is adopted shall be given precedence and shall prevail over the amendments in this act to the extent that such acts are in conflict with this act.”

Quoted in

Rocky Mt. Turbines, Inc. v. 660 Syndicate, Inc., 623 P.2d 758, 1981 Wyo. LEXIS 289 (Wyo. 1981).

§ 29-7-104. Termination of lien; effect thereof on claimant's right of possession.

  1. A lien under W.S. 29-7-101 through 29-7-106 terminates:
    1. Upon a lienor’s voluntary surrender of possession of the property, unless a lien statement has previously been filed as provided in W.S. 29-7-103 ;
    2. One hundred eighty (180) days after the date upon which the work, services, materials and feed giving rise to the lien were performed or furnished unless a lien statement has previously been filed as provided by W.S. 29-7-103 ; and
    3. One hundred eighty (180) days after a lien statement is filed as provided in W.S. 29-7-103, unless action to enforce and foreclose the lien has commenced.
  2. Upon termination of a lien, the lien claimant has no further right to possession of the property and no further interest therein.

History. Laws 1967, ch. 89, § 4; W.S. 1977, § 29-7-104 ; Laws 1981, Sp. Sess., ch. 17, § 2.

This section fails to define when storage charges “become due and payable,” and the supreme court will not read into the statute an arbitrary time limit. Minnehoma Fin. Co. v. Pauli, 565 P.2d 835, 1977 Wyo. LEXIS 308 (Wyo. 1977).

Storage is continuing service. —

Storage, unlike the performance of specific services, is a continuing service. In other words, the service does not terminate merely because charges for it have accrued. Minnehoma Fin. Co. v. Pauli, 565 P.2d 835, 1977 Wyo. LEXIS 308 (Wyo. 1977).

Quoted in

Rocky Mt. Turbines, Inc. v. 660 Syndicate, Inc., 623 P.2d 758, 1981 Wyo. LEXIS 289 (Wyo. 1981).

Cited in

Coones v. FDIC, 848 P.2d 783, 1993 Wyo. LEXIS 48 (Wyo. 1993).

Am. Jur. 2d, ALR and C.J.S. references. —

Loss of garageman's lien on repaired vehicle by owner's use of vehicle, 74 ALR4th 90.

§ 29-7-105. Repossession; enforcement of lien by sale; notice thereof to known claimants; satisfaction by any claimant; title of good faith purchaser; disposition of proceeds; additional creditors' rights; liability for noncompliance with section; “commercially reasonable”.

  1. Subject to the termination of a lien as provided in W.S. 29-7-104 , a lienor who has surrendered possession involuntarily has the right to repossess the property subject to the lien. In repossessing a lienor may proceed without judicial process if this can be done without breach of the peace. A lienor may also replevy the property or use any other judicial action available.
  2. A lien arising under W.S. 29-7-101 through 29-7-106 may be enforced by public or private sale of the property en bloc or in parcels at a time or place and on terms which are commercially reasonable after mailing by certified mail, return receipt requested, to their last known address a notice to all persons known to claim an interest in the property. The notification shall include:
    1. A statement of the amount due;
    2. The nature of the proposed sale; and
    3. The time and place of any public sale.
  3. Before any sale pursuant to this section any person claiming a right in the property may pay the amount necessary to satisfy the lien and the reasonable expenses incurred under this section.
  4. The lien claimant may buy at any public sale pursuant to this section.
  5. A purchaser in good faith of property sold to enforce a lien under W.S. 29-7-101 through 29-7-106 takes the property free of any rights of persons against whom the lien was valid, despite noncompliance by the lien claimant with the requirements of this section.
  6. A lien claimant may satisfy his lien from the proceeds of any sale pursuant to this section but shall hold the balance, if any, for delivery on demand to the owner of the property or any person entitled thereto. The owner or any other person demanding delivery of the balance shall furnish to the lien claimant reasonable evidence of his right to take delivery.
  7. The rights provided by W.S. 29-7-101 through 29-7-106 shall be in addition to all other rights allowed by law to a creditor against his debtor.
  8. A lien under W.S. 29-7-101 through 29-7-106 may also be enforced in accordance with the procedure set forth in W.S. 34.1-7-210(b).
  9. A lien claimant is liable for damages caused by failure to comply with this section.
  10. The fact a better price could be obtained by a sale at a different time or in a different method from that selected by the lien claimant is not sufficient to establish a sale as not made in a commercially reasonable manner.

History. Laws 1967, ch. 89, § 5; W.S. 1977, § 29-7-105 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2004, ch. 130, § 1.

The 2004 amendment, in (b), substituted “en bloc” for “in bloc.”

Laws 2004, ch. 130, § 4, makes the act effective immediately upon completion of all acts necessary for a bill to become law as provided by art. 4, § 8, Wyo. Const. Approved March 19, 2004.

Editor's notes. —

There is no subsection (i) in this section as it appears in the printed acts.

Conflicting legislation. —

Laws 2004, ch. 130, § 3, provides: “Any other act adopted by the Wyoming legislature during the same session in which this act is adopted shall be given precedence and shall prevail over the amendments in this act to the extent that such acts are in conflict with this act.”

Attorney fees not authorized by this section. —

When the court issued a writ of replevin requiring appellee to relinquish possession of a vehicle previously purchased by appellant, the court did not abuse its discretion in denying appellant's request for attorney fees because Wyoming follows the American rule and the legislature has elected not to include attorney fees with an award of damages for a violation of this section. Dave v. Valdez, 2012 WY 59, 275 P.3d 485, 2012 Wyo. LEXIS 62 (Wyo. 2012).

Stated in

Minnehoma Fin. Co. v. Pauli, 565 P.2d 835, 1977 Wyo. LEXIS 308 (Wyo. 1977).

Cited in

Katona v. City of Cheyenne, 686 F. Supp. 287, 1988 U.S. Dist. LEXIS 4215 (D. Wyo. 1988).

§ 29-7-106. Priority of lien.

  1. A lien pursuant to W.S. 29-7-101 through 29-7-106 except as otherwise specifically provided therein shall be prior to all other liens, encumbrances and security interests if the property claimed is in possession of the lien claimant.
  2. If the property is not in possession of the lien claimant, a lien under W.S. 29-7-101 through 29-7-106 shall be prior to all other liens, encumbrances and security interests, except for a subsequent lien claimant in possession under W.S. 29-7-101 through 29-7-106 or a lien created under W.S. 29-8-102 relating to liens for the production of farm products under contracts executed, entered into, renewed or substantively amended after July 1, 2001.

History. Laws 1967, ch. 89, § 6; W.S. 1977, § 29-7-106 ; Laws 1981, Sp. Sess., ch. 17, § 2; 2001, ch. 126, § 2.

Owner may not impose lien. —

Under the plain and ordinary language contained in § 29-7-101(a) and subsection (a) of this section, only a third-party creditor, and not the owner, may impose a lien upon the secured property. Coones v. FDIC, 894 P.2d 613, 1995 Wyo. LEXIS 71 (Wyo. 1995).

Article 2. Breeders

§ 29-7-201. Owner of male animal to have lien on female animal and offspring.

The owner of a male animal shall have a lien upon any female animal bred to the male and also upon any offspring begotten by the male for the sum stipulated to be paid for the service.

History. Laws 1890, ch. 74, § 1; R.S. 1899, § 2861; C.S. 1910, § 3771; C.S. 1920, § 4820; R.S. 1931, § 66-301; C.S. 1945, § 56-1601; W.S. 1957, § 11-491; W.S. 1977, § 11-28-301; Rev. W.S. 1977, § 29-7-107; Laws 1978, ch. 32, § 2; 1981, Sp. Sess., ch. 17, § 2.

§ 29-7-202. Notice of lien to be filed; time and place; form; filing by county clerk; release; renewal.

  1. A notice of a breeder’s lien shall within ninety (90) days after the date of the service be filed in the office of the secretary of state. The notice shall be in the following format:

    Notice of Breeder's Lien The State of Wyoming County of ss. I, , being first duly sworn, upon my oath depose and say I am the lawful owner (or duly authorized agent of the lawful owner) of (description of male animal). On (or between) the day of , A.D. (year) and the day of , (year), the services of the male animal were had upon the following described female animals: The above services were rendered at the request of (for and on behalf of ), the lawful owner of the female animals. The fee agreed upon for these services was dollars. There is now due to from for these services, the sum of dollars. Ninety (90) days have not elapsed since the date of the services, and claim a breeder's lien on the property for this amount. Subscribed in my presence and sworn to before me this day of , A.D. (year). Notarial Officer. My commission expires

    Click to view

  2. The secretary of state on presentation shall file this instrument in his office in the same manner as financing statements are required to be filed under the Uniform Commercial Code.
  3. All breeders’ liens shall be released in the same manner as financing statements under the Uniform Commercial Code.
  4. If the owner of the male animal does not wish to take advantage of W.S. 29-7-204 he may renew the lien in the same manner in which secured interests are renewed pursuant to the Uniform Commercial Code.

History. Laws 1890, ch. 74, § 2; R.S. 1899, § 2862; Laws 1907, ch. 59, § 1; C.S. 1910, § 3772; C.S. 1920, § 4821; R.S. 1931, § 66-302; C.S. 1945, § 56-1602; W.S. 1957, § 11-492; W.S. 1977, § 11-28-302; Rev. W.S. 1977, § 29-7-108; Laws 1978, ch. 32, § 2; 1981, Sp. Sess., ch. 17, § 2; 1999, ch. 150, § 2; 2004, ch. 24, § 1; 2011, ch. 113, § 2.

The 2004 amendment, effective July 1, 2004, in (a), substituted “secretary of state” for “county clerk of the county in which the female animal or the offspring is held or pastured”; and, in (b), substituted “secretary of state” for “county clerk.”

The 2011 amendment, effective July 1, 2011, in (a), substituted “Notarial Officer” for “Notary Public” in the notice.

§ 29-7-203. Priority of liens.

The lien herein given is prior to and shall take precedence over any lien or encumbrance given subsequent to the service unless the lien is created pursuant to W.S. 29-8-102 relating to liens for the production of farm products under contracts executed, entered into, renewed or substantively amended after July 1, 2001.

History. Laws 1890, ch. 74, § 3; R.S. 1899, § 2863; C.S. 1910, § 3773; C.S. 1920, § 4822; R.S. 1931, § 66-303; C.S. 1945, § 56-1603; W.S. 1957, § 11-493; W.S. 1977, § 11-28-303; Rev. W.S. 1977, § 29-7-109; Laws 1978, ch. 32, § 2; 1981, Sp. Sess., ch. 17, § 2; 2001, ch. 126, § 2.

§ 29-7-204. Possession and sale of female animal or offspring by lien claimant.

At any time after default of payment for services rendered and within one (1) year after the service, the owner of the lien may take possession of any female animal or offspring upon which a lien exists in accordance with law and sell it as provided by W.S. 29-7-205 .

History. Laws 1890, ch. 74, § 4; R.S. 1899, § 2864; C.S. 1910, § 3774; C.S. 1920, § 4823; R.S. 1931, § 66-304; C.S. 1945, § 56-1604; W.S. 1957, § 11-494; W.S. 1977, § 11-28-304; Rev. W.S. 1977, § 29-7-110; Laws 1978, ch. 32, § 2; 1981, Sp. Sess., ch. 17, § 2.

§ 29-7-205. Sale at auction; publication or posting of notice; contents thereof; new notice required in case of adjournment; lien claimant may purchase; bill of sale to be filed.

  1. A sale shall be made at public auction. The lienholder shall first give ten (10) days notice in any newspaper published in the county where the notice of lien is filed. If no newspaper is published in the county the notice shall be posted for two (2) weeks in at least three (3) public places in the county, one (1) of which shall be at the front door of the courthouse. The notice shall:
    1. Describe the animal or animals to be sold;
    2. State the amount of money claimed to be due;
    3. State when the services were rendered; and
    4. State the exact time and place of the sale.
  2. If for any reason it is necessary to adjourn the sale, new notices shall be given as in the first instance required.
  3. A lien claimant is not prevented from purchasing at a sale because of his owning the lien on the animal sold.
  4. The purchaser shall take from the person selling any female animal or offspring a bill of sale which shall contain the substance of the notice of sale, the date of sale and the consideration. The bill of sale shall be filed in the office of the secretary of state, and shall be provided to a Wyoming brand inspector upon a change of ownership inspection pursuant to W.S. 11-20-203 .

History. Laws 1890, ch. 74, § 5; R.S. 1899, § 2865; C.S. 1910, § 3775; C.S. 1920, § 4824; R.S. 1931, § 66-305; C.S. 1945, § 56-1605; W.S. 1957, § 11-495; W.S. 1977, § 11-28-305; Rev. W.S. 1977, § 29-7-111; Laws 1978, ch. 32, § 2; 1981, Sp. Sess., ch. 17, § 2; 2004, ch. 24, § 1.

The 2004 amendment, effective July 1, 2004, in (d), substituted “secretary of state, and shall be provided to a Wyoming brand inspector upon a change of ownership inspection pursuant to W.S. 11-20-203 ” for “county clerk where the notice of lien was filed.”

§ 29-7-206. Sale at auction; offspring to be sold first; disposition of proceeds; remedies not exclusive.

If a female animal and her offspring are taken under a lien, the offspring shall be sold first. If the proceeds are sufficient to pay the expense incurred in taking possession under the lien, the filing fee and the costs of notices, then the female animal shall not be sold. After deducting the expense from the proceeds of any sale, the remainder of the proceeds, if any, shall be returned to the person entitled to them. The lien herein given shall not exclude any holder of a lien from abandoning it and recovering the amount due him by an action at law.

History. Laws 1890, ch. 74, § 6; R.S. 1899, § 2866; C.S. 1910, § 3776; C.S. 1920, § 4825; R.S. 1931, § 66-306; C.S. 1945, § 56-1606; W.S. 1957, § 11-496; W.S. 1977, § 11-28-306; Rev. W.S. 1977, § 29-7-112; Laws 1978, ch. 32, § 2; 1981, Sp. Sess., ch. 17, § 2.

§ 29-7-207. Selling or removing encumbered property without lienholder's consent; penalty.

Any owner of a female animal or offspring on which a lien exists under W.S. 29-7-201 through 29-7-207 who disposes of any female animal or offspring before the lien expires or is satisfied or who removes the female animal or offspring with intent to deprive a lien claimant of his lien or with intent to damage an innocent purchaser, and does so without first having obtained the consent of the lienholder to the disposition is guilty of a misdemeanor. On conviction he may be fined not more than seven hundred fifty dollars ($750.00).

History. Laws 1890, ch. 74, § 7; R.S. 1899, § 2867; C.S. 1910, § 3777; C.S. 1920, § 4826; R.S. 1931, § 66-307; C.S. 1945, § 56-1607; W.S. 1957, § 11-497; W.S. 1977, § 11-28-307; Rev. W.S. 1977, § 29-7-113; Laws 1978, ch. 32, § 2; 1981, Sp. Sess., ch. 17, § 2; 2004, ch. 24, § 1.

The 2004 amendment, effective July 1, 2004, deleted “out of the county in which the notice of lien is filed” following “the female animal or offspring.”

Article 3. House Trailers

§ 29-7-301. Persons entitled to lien; notice and priority thereof; removal of trailer by lienor; exception; enforcement and foreclosure of lien; “house trailer”.

  1. Any person leasing or renting space for a house trailer site shall have a lien on any house trailer thereon situated for unpaid lease or rental payments and for other unpaid charges due the lessor under the terms or conditions of any lease or rental agreement. The lien shall be effective after the lessee has defaulted in payments as provided in the written rental or lease agreement. Notice of the lien shall be given by the lessor by causing notice in writing to be posted conspicuously on the mobile home. The lien provided by this section shall have priority over all other liens except a previously perfected security interest in the mobile home.
  2. At any time after thirty (30) days after notice is given the lessor may remove the house trailer from the leased or rented site and retain the lien as provided by this section. On removal, reasonable charges for the removal and storage may be assessed against the house trailer.
  3. Notwithstanding the provisions of subsection (b) of this section, a house trailer shall not be removed pursuant to this section if it is occupied by the lessee. In this case the lessor has a remedy at law.
  4. The lien provided by this section may be enforced and foreclosed as security agreements are enforced under W.S. 34.1-1-101 through 34.1-10-104.
  5. As used in this section “house trailer” shall be defined as in W.S. 31-5-102(a)(xv).

History. Laws 1981, Sp. Sess., ch. 17, § 1; 2006, ch. 114, § 1.

The 2006 amendment, substituted “31-5-102(a)(xv)” for “35-1-102(a)(xvi)” in (e).

Laws 2006, ch. 114, § 5, makes the act effective immediately upon completion of all acts necessary for a bill to become law as provided by art. 4, § 8, Wyo. Const. Approved March 24, 2006.

Conflicting legislation. —

Laws 2006, ch. 114, § 3, provides: “[A]ny other act adopted by the Wyoming legislature during the same session in which this act is adopted shall be given precedence and shall prevail over the amendments in this act to the extent that such acts are in conflict with this act.”

Quoted in

Sheridan Com. Park v. Briggs, 848 P.2d 811, 1993 Wyo. LEXIS 44 (Wyo. 1993).

Am. Jur. 2d, ALR and C.J.S. references. —

Loss of garageman's lien on repaired vehicle by owner's use of vehicle, 74 ALR4th 90.

Validity, construction, and application of mobile home eviction statutes, 43 ALR5th 705.

Chapter 8 Agricultural Producer's Liens

Editor's notes. —

As originally enacted, § 29-8-109 (b), provided that this chapter would be repealed effective July 1, 2003. Laws 2003, ch. 63, § 1, amended § 29-8-109 to repeal subsection (b).

§ 29-8-101. Definitions.

  1. As used in this article:
    1. “Commodity dealer” means a person who engages in a business involving or, as part of the business, participates in buying, exchanging, negotiating or soliciting the sale, resale, exchange, production or transfer of any farm product in the state of Wyoming. The term does not include:
      1. A person engaged solely in storing, shipping or handling farm products for hire;
      2. A person who buys farm products from a licensed commodity dealer;
      3. A person who does not purchase more than thirty thousand dollars ($30,000.00) worth of farm products from producers during a licensing year;
      4. A person who is the producer of farm products that the person actually plants, nurtures and harvests;
      5. A person whose trading in farm products is limited to trading in commodity futures on a recognized futures exchange; or
      6. A person who buys farm products used exclusively for the feeding of livestock and not for resale.
    2. “Contractor” means a person who owns a farm product that is produced by a producer according to a contract;
    3. “Farm products” means all crops, crop products, plants or portions thereof, whether or not they are cleaned, processed, treated, reconditioned, rolled, mixed or combined in any fashion. Farm products shall not mean livestock;
    4. “Person” means an individual, trust, partnership, business trust, corporation or unincorporated association or any other legal or commercial entity;
    5. “Processor” means any person engaged in the business of processing or manufacturing any farm product and who takes possession or control of any farm product for the purpose of processing, cleaning, selling or storing it;
    6. “Producer” means the owner, tenant or operator of land located in the state of Wyoming who has an interest in or receives all or part of the proceeds from the assignment, sale, transfer, exchange or production of farm products grown or produced on that land;
    7. “Public warehouse” or “warehouse” means an elevator, mill, warehouse, subterminal grain warehouse, public warehouse or other structure or facility in which, for compensation, farm products are received for storage, handling, processing or shipment. The term includes facilities that commingle different lots of farm products;
    8. “This act” means W.S. 29-8-101 through 29-8-109 .

History. Laws 2001, ch. 126, § 1.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

§ 29-8-102. Producer's liens.

  1. W.S. 29-1-103 through 29-7-301 shall not apply to liens filed under this act.
  2. A producer has a lien on all farm products grown or produced by it and on all proceeds from the assignment, sale, transfer, exchange or other disposition thereof until the producer is paid in full all amounts due the producer for its assignment, sale, transfer, exchange, other disposition or production of the farm products.

History. Laws 2001, ch. 126, § 1; 2010, ch. 92, § 2.

The 2010 amendment, effective July 1, 2011, substituted “W.S. 29-1-103 ” for “W.S. 29-1-101 .”

Meaning of “this act.” —

For the definition of “this act,” referred to in this section, see § 29-8-101(a)(viii).

§ 29-8-103. Notice; filing of notice of claim; contents.

  1. A lien created under W.S. 29-8-102 attaches when the farm product is delivered from the producer to the processor, contractor, warehouse operator or commodity dealer.
  2. A person claiming a lien created by this act shall file a written notice of claim of lien with the office of the secretary of state not later than one hundred eighty (180) days after the lien attaches.
  3. The notice of claim of lien required under subsection (b) of this section shall be in the form of a financing statement acceptable for filing by the office of the secretary of state. The signature of the processor, contractor, warehouse operator or commodity dealer shall not be required. The written notice of claim filed under subsection (c) of this section shall contain:
    1. A true statement of the lienholder’s claim;
    2. A description of the farm product delivered sufficient for identification;
    3. The lienholder’s name, address and phone number, establishing them as a secured party; and
    4. The name and address of the processor, contractor, warehouse operator or commodity dealer, establishing them as the debtor.
  4. The secretary of state shall keep a record of notices filed under this section under an index of agricultural liens.
  5. The secretary of state shall charge a fee not exceeding the cost of providing the service for filing of notices and requests for copies of such notices.
  6. When a lienholder files a notice of claim of lien as required by this section, the lienholder shall send a copy of the notice to the processor, contractor, warehouse operator or commodity dealer by registered or certified mail.
  7. When a lienholder files a notice of claim of lien as required by this section the lienholder shall send a copy of the notice to all holders of security interests in the farm product described in the notice of claim who duly perfected such security interests by filing notice thereof with the secretary of state. The notice shall be mailed to holders of perfected security interests within thirty (30) days after the date of filing the notice of claim.
  8. A lien which has attached under subsection (a) of this section is perfected upon the completion of the requirements of subsections (a) through (h) of this section. If a person entitled to a lien under this section does not properly file a notice of claim or properly notify all holders of security interests of the lien within the time required by this section, the person waives the right to the lien.

History. Laws 2001, ch. 126, § 1.

Meaning of “this act.” —

For the definition of “this act,” referred to in this section, see § 29-8-101(a)(viii).

§ 29-8-104. Extent of lien; priority.

  1. The lien shall be to the extent of:
    1. The agreed price, if any, pursuant to the terms of any contract or for the market value at the time of transfer of ownership if not agreed;
    2. If the farm product has not been sold or processed by the processor, contractor, warehouse operator or commodity dealer the lien shall be on the farm product;
    3. If the farm product is sold or processed by the processor, contractor, warehouse operator or commodity dealer the lien shall be on the cash proceeds from the sale. For purposes of this paragraph, cash proceeds held by the processor, contractor, warehouse operator or commodity dealer shall be deemed to be cash proceeds from the sale regardless of whether it is identifiable cash proceeds;
    4. If the farm product is processed by the processor, contractor, warehouse operator or commodity dealer and there is no property of the type described in paragraph (ii) or (iii) of this subsection to which the lien can attach, then the lien shall extend to any property of the processor, contractor, warehouse operator or commodity dealer that may be subject to a security interest as provided by W.S. 34.1-9-109.
  2. A perfected lien under paragraph (a)(ii) or (iii) of this section shall be preferred to, and have priority over, a lien or security interest in favor of a creditor of the processor, contractor, warehouse operator or commodity dealer regardless of the time when the creditor’s lien or security interest attached to the farm products or the proceeds thereof or therefrom. The priority of a perfected lien under paragraph (a)(iv) of this section shall be determined by the date on which the lien is filed as required by this act, and it shall not have priority over other perfected liens on the same property which have been perfected prior to the filing date.

History. Laws 2001, ch. 126, § 1; ch. 177, § 4.

Meaning of “this act.” —

For the definition of “this act,” referred to in this section, see § 29-8-101(a)(viii).

§ 29-8-105. Duration.

  1. A perfected lien created by this act remains in effect until either the lienholder receives the full amount due it for the farm products, including reasonable costs and attorneys’ fees incurred in enforcing the lien, or for a period of two hundred ten (210) days from the date the lien becomes perfected as provided in this act.
  2. All actions to foreclose or enforce a lien under this chapter shall be commenced within two hundred forty (240) days after the filing of the lien statement. No lien shall continue to exist except by virtue of the provisions of this chapter for more than two hundred forty (240) days after the lien is filed unless an action to foreclose the lien is instituted.
  3. Whenever any debt which is a lien pursuant to this act is paid and satisfied, the lien claimant shall file notice of satisfaction of the claim of lien in the secretary of state’s office.
  4. In addition to any actual damages, any creditor refusing or neglecting to enter satisfaction within thirty (30) days after payment as provided by subsection (c) of this section and after having received by certified or registered mail a request in writing for the entering of satisfaction is liable for damages of not less than one-tenth of one percent (.10%) of the original principal amount of the debt per day until such time as the lienholder enters satisfaction. The additional damages authorized by this section shall not exceed one hundred dollars ($100.00) per day.

History. Laws 2001, ch. 126, § 1.

Meaning of “this act.” —

For the definition of “this act” referred to in this section, see § 29-8-101(a)(viii).

§ 29-8-106. Waivers unenforceable.

Any provision of a contract which waives a producer’s right or an obligation of a party established by this act is void and unenforceable. This section does not affect other provisions of the contract or related document, policy or agreement which can be given effect without the voided provision.

History. Laws 2001, ch. 126, § 1.

Meaning of “this act.” —

For the definition of “this act,” referred to in this section, see § 29-8-101(a)(viii).

§ 29-8-107. Choice of law.

Any condition, stipulation or provision requiring the application of the law of another state in lieu of this act is void and unenforceable.

History. Laws 2001, ch. 126, § 1.

Meaning of “this act.” —

For the definition of “this act,” referred to in this section, see § 29-8-101(a)(viii).

§ 29-8-108. Damages, fees, costs and injunctive relief.

  1. A producer who suffers damages because of a violation of this act may obtain appropriate legal and equitable relief, including damages, as a suit in common law pursuant to the Wyoming Rules of Civil Procedure.
  2. In any action by a producer to enforce a perfected lien created by this act, the court shall award the producer who is the prevailing party reasonable attorneys’ fees and other litigation costs and expenses. The payment of any such award shall be secured in the same manner as a lien created and perfected under this act.
  3. In order to obtain injunctive relief, a producer is not required to post a bond, prove the absence of an adequate remedy at law, or show the existence of special circumstances, unless the court for good cause otherwise orders. The court may order any form of prohibitory or mandatory relief that is appropriate under principles of equity, including but not limited to, issuing a temporary or permanent restraining order.

History. Laws 2001, ch. 126, § 1.

Meaning of “this act.” —

For the definition of “this act,” referred to in this section, see § 29-8-101(a)(viii).

§ 29-8-109. Applicability of act.

  1. This act applies to contracts executed, entered into, renewed or substantively amended on or after July 1, 2001.
  2. Repealed by Laws 2003, ch. 63, § 1.

History. Laws 2001, ch. 126, § 1; 2003, ch. 63, § 1.

Meaning of “this act.” —

For the definition of “[t]his act,” referred to in this section, see § 29-8-101(a)(viii).

Chapter 9 Miscellaneous Liens

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

§ 29-9-101. Lien of state on realty of debtor.

The amount of every account audited, adjusted and found due to the state including penalties and interest is a lien upon the real property of the person charged with the debt. The lien shall be in effect from the time suit commences for the recovery of the debt.

History. Laws 2010, ch. 92, § 1.

§ 29-9-102. Lien of attorneys on papers and monies of clients.

  1. For professional services performed on behalf of a client, an attorney shall have a lien for compensation due him from the time of giving notice of the lien. The attorney’s lien attaches upon:
    1. Any papers or money of his client which have come into his possession;
    2. Money due his client and in the possession of an adverse party.
  2. Notice as required by subsection (a) of this section to be given to any person against whom the lien is asserted shall be given by certified mail, return receipt requested.

History. Laws 2010, ch. 92, § 1.

Improper filing of attorney’s lien. —

Attorney violated professional conduct rules and was suspended for 30 days for misrepresentations in filing a lien statement where the lien was filed under a statute that applied to improvements to real property, and no notice was provided. Moreover, the attorney failed to make any limitation to exclude the assets of a spouse, and she attached an inaccurate and unreasonable billing statement to the sworn lien statement that was filed with a county clerk. Bd. of Prof'l Responsibility v. Casper, 2014 WY 22, 318 P.3d 790, 2014 Wyo. LEXIS 27 (Wyo. 2014).

Chapter 10 Forms

Effective date. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

§ 29-10-101. Preliminary notice of right to lien; lien waiver form.

  1. Preliminary notice of right to a lien shall be sent to the record owner of the property against which the lien may be filed and shall be completed in substantially the following form: Note to Lien Claimant: This form, if filled out correctly and sent within the time periods specified in , constitutes prima facie evidence that you have provided the content of the notice required by . If you have any questions regarding how to fill out this form or whether it has been filled out properly, you should consult a attorney. W.S. 29-2-112 W.S. 29-2-112 (a)(i) NOTICE TO OWNER The undersigned party is providing work or materials to the property described below. Failure of payment due and owing to a contractor, subcontractor or materialman for work performed or materials provided to the project located on the property can result in the filing of a lien against the property. To avoid this result, when paying for labor and materials you may ask the contractor, subcontractor or materialman for “lien waivers” from all persons supplying materials or services. Failure to secure lien waivers may result in your paying for labor and materials twice. A form of lien waiver is attached to this notice. Name, address and telephone number of contractor, subcontractor or materialman, and contact person: MATERIALS PROVIDED OR WORK PERFORMED: PROPERTY DESCRIPTION: ADDRESS: LEGAL DESCRIPTION: SIGNED: DATE: Click to view
  2. The form for waiver of a lien shall be completed in substantially the following form:

    Note to lien claimant: Signing this form has legal implications. If you have any questions regarding how to complete this form or whether it has been properly completed, you should consult an attorney. LIEN WAIVER TO: PROJECT: FROM: DATE: PAYMENT: $ In consideration of the PAYMENT received to date, the undersigned does hereby waive, release, and relinquish any and all claim and/or right of lien against the project and the real property improvements thereto for labor and/or materials furnished for use in construction of the project; provided however, the undersigned reserves all claims and/or rights of lien as to monies withheld as retainage in the amount of $, and any labor and/or materials hereafter furnished for which payment has not yet been made. The undersigned has not been paid the sum of $ for work performed and/or materials provided under contract on this project and retains the right to file a lien against the property and pursue any and all actions to recover the full amount due, including any and all equitable claims. The undersigned acknowledges receipt of payment for work performed or materials provided and acknowledges that this waiver may be relied upon by the owner even if the undersigned accepts payment in uncertified funds and such payment is subsequently dishonored or revoked, in which case this lien waiver shall remain in full force and effect. The foregoing waiver shall not apply, however, if payment tendered by the owner is dishonored or revoked. By: subcontractor/materialman/employee Title: Date: STATE OF COUNTY OF ss. This instrument was acknowledged before me on this day of, 20, by (name of person) as lien claimant or (title, position or type of authority granted by lien claimant) of (lien claimant). IN WITNESS THEREOF, I have hereunto set my hand and affixed my official seal on the day and year last above written. Notarial officer My Commission Expires: Seal:

    Click to view

History. Laws 2010, ch. 92, § 1.

§ 29-10-102. Form for notice of intention to file lien.

  1. Notice of intention to file a lien shall be sent to the record owner of the property against which the lien may be filed or his agent and shall be completed in substantially the following form: Note to lien claimant: This form, if filled out correctly and sent within the time periods specified in W.S. 29-2-107 constitutes prima facie evidence that you have provided the contents of the notice required by W.S. 29-2-107 (a). If you have any questions regarding how to fill out this form or whether it has been filled out properly, you should consult an attorney. CERTIFIED MAIL, RETURN RECEIPT REQUESTED To: Record owner or agent of owner (note: If there is more than one (1) owner, use a form for each owner) Date: , 20 Re: Notice of Intention to File Lien You are hereby notified pursuant to that intends to file a lien against your property. W.S. 29-2-107 (hereinafter the “lien claimant”) The amount of the lien claim is $ This amount is due from pursuant to a contract with the lien claimant under which the lien claimant performed work or supplied materials for the work. (person/entity whose actions have caused a lien to be filed) If we are unable to resolve this matter within twenty (20) days from the date of this notice, the lien claimant intends to file the lien statement asserting a lien against your property. cc: Click to view

History. Laws 2010, ch 92 § 1; 2011, ch. 130, § 1; 2013, ch. 150, § 1.

Effective dates. —

Laws 2010, ch. 92, § 5, makes the act effective July 1, 2011.

The 2011 amendment, effective July 1, 2011, in (a), substituted “twenty (20) days” for “thirty (30) days” in the form.

The 2013 amendment, effective July 1, 2013, substituted “or his agent” for “sent to the lien claimant” in (a).

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

§ 29-10-103. Form of notice of filing lien.

  1. Notice of filing a lien shall be sent to the record owner of the property against which the lien shall be filed and shall be completed in substantially the following form: Note to lien claimant: This form, if filled out correctly and sent within the time periods specified in constitutes prima facie evidence that you have provided the content of the notice required by . If you have any questions regarding how to fill out this form or whether it has been filled out properly, you should consult an attorney. W.S. 29-2-107 W.S. 29-1-312 (c) CERTIFIED MAIL, RETURN RECEIPT REQUESTED To: Record owner or agent of owner (note: If there is more than one (1) owner, use a form for each owner) Date:, 20 Re: Notice of Filing Lien This letter shall serve as notice to you pursuant to that (hereinafter the “lien claimant”) has filed a lien against your property. W.S. 29-1-312 cc: Click to view

History. Laws 2010, ch. 92, § 1.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

§ 29-10-104. Form for lien statement.

  1. The lien statement shall be filed with the county clerk’s office in the county where the property against which the lien is filed is located and shall be completed in substantially the following form: Note to lien claimant: This form, if filled out correctly and filed with the county clerk's office within the time periods specified in constitutes prima facie evidence that you have provided the content of the lien statement required by and (f). If you have any questions regarding how to fill out this form or whether it has been filled out properly, you should consult an attorney. W.S. 29-2-106 W.S. 29-1-312 (b) STATE OF COUNTY OF ss. LIEN STATEMENT Pursuant to the provisions of relating to lien statements, the undersigned hereby files this lien statement and swears as follows: W.S. 29-1-312 1. Name and address of lien claimant: 2. The amount claimed to be due and owing: $, plus pre-judgment interest at a rate of % (if applicable), and attorneys' fees and costs incurred by lien claimant in the collection of this amount. 3. The names and addresses of the persons against whose properties the lien is filed include: 4. An itemized list setting forth and describing the work performed or materials furnished by the lien claimant: The amounts due and owing from for the work performed and/or materials provided are set forth in the actual invoices, or if no invoices exist, then a summary, attached hereto as Exhibit “A”. 5. The name of the persons whom the lien claimant asserts is/are obligated to pay the debt secured by the lien: 6. The lien claimant last performed work, or furnished materials, for which the lien claimant asserts a lien on the day of , 20. 7. The legal description of the real property where the lien claimant performed work or furnished materials is set forth in Exhibit “B”, attached hereto. 8. A true and accurate copy of the written contract, if available, under which the lien claimant performed work or furnished materials is attached hereto as Exhibit “C”. If the contract was oral or is too extensive, the parties to the contract and contract terms are described below: A copy of the written contract, if applicable, is located at the following address: DATED this day of , 20. Name of lien claimant: By: Signature: Title: Note to Notarial officer: If the lien claimant is a legal entity formed under Title 17 of the Wyoming Statutes or other applicable law, use the first jurat. If the lien claimant is an individual or sole proprietor, use the second jurat. (Alternative 1:) STATE OF COUNTY OF ss. On this day of , 20, subscribed and sworn to before me personally appeared (name of signatory), to me personally known, who has read the foregoing Lien Statement and knows the contents thereof and the facts are true to the best of his/her knowledge, and being by me duly sworn, did state that he/she is the (title, position or type of authority granted by lien claimant) of (lien claimant) and that this lien statement was signed and sealed on behalf of the lien claimant by authority granted to the signatory by the lien claimant. Witness my hand and official seal. Notarial officer My Commission Expires: Seal: (Alternative 2:) STATE OF COUNTY OF ss. On this day of, 20, subscribed and sworn to before me personally appeared (name of signatory), to me personally known, who has read the foregoing Lien Statement and knows the contents thereof and the facts are true to the best of his/her knowledge, and being by me duly sworn, did state that the lien statement to be the free act and deed of the lien claimant. Witness my hand and official seal. Notarial officer My Commission Expires: Seal: Click to view

History. Laws 2010, ch. 92, § 1.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

§ 29-10-105. Form for notice of substantial completion of the project.

  1. The form for notice of substantial completion of the project may be filed with the county clerk in the county where the project is located in accordance with W.S. 29-2-106(c). After the notice has been duly recorded, the record owner shall send a copy of the notice to all contractors, subcontractors and materialmen who provided the record owner with preliminary notice pursuant to W.S. 29-2-112 within five (5) days after recording the notice under this section. The form shall be completed in substantially the following form: (In bold face type) This notice creates a presumption under that the period for filing a lien shall begin to run on the date the notice was recorded. If the recipient of the notice has not been paid in full, any lien to be filed on the property to secure full payment shall be filed by contractors within one hundred fifty (150) days of the date the notice was recorded and within one hundred twenty (120) days the notice was recorded for materialmen. W.S. 29-2-106(c) STATE OF COUNTY OF ss. NOTICE OF SUBSTANTIAL COMPLETION OF THE PROJECT Pursuant to the provisions of , the undersigned hereby files its notice of substantial completion of the project, filed with the Clerk of County on the day of , 20 , commencing at Page of Book . W.S. 29-2-106(c) Dated this day of , 20 . Name of record owner: By: Signature: Title: Note to Notarial Officer: If the record owner is a legal entity formed under Title 17 of the Wyoming Statutes or other applicable law, use the first jurat. If the record owner is an individual or sole proprietor, use the second jurat. (Alternative 1:) STATE OF COUNTY OF ss. On this day of , 20 , subscribed and sworn to before me personally appeared (name of signatory), to me personally known, who has read the foregoing Notice of Substantial Completion of the Project and knows the contents thereof and the facts are true to the best of his/her knowledge, and being by me duly sworn, did state that he/she is the (title, position or type of authority granted by record owner) of (record owner) and that this Notice of Substantial Completion of the Project was signed and sealed on behalf of the record owner by authority granted to the signatory by the record owner. Witness my hand and official seal. Notarial officer My Commission Expires: Seal: (Alternative 2:) STATE OF COUNTY OF ss. On this day of , 20 , subscribed and sworn to before me personally appeared (name of signatory), to me personally known, who has read the foregoing Notice of Substantial Completion of the Project and knows the contents thereof and the facts are true to the best of his/her knowledge, and being by me duly sworn, did state that the Notice of Substantial Completion of the Project to be the free act and deed of the record owner Witness my hand and official seal. Notarial officer My Commission Expires: Seal: Click to view

History. Laws 2010, ch. 92, § 1.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.

§ 29-10-106. Form for notice of satisfaction of lien.

  1. The form for notice of satisfaction of a lien shall be filed with the county clerk’s office in the county where the property against which the lien was filed is located, sent to the record owner and shall be completed in substantially the following form: Note to lien claimant: This form, if filled out correctly and filed with the county clerk's office within the time period specified in constitutes prima facie evidence that you have fulfilled your obligation to file a notice of satisfaction of the lien required by and . If you have any questions regarding how to fill out this form or whether it has been filled out properly, you should consult an attorney. W.S. 29-1-314 W.S. 29-1-313 29-1-314 STATE OF COUNTY OF ss. NOTICE OF SATISFACTION OF LIEN Pursuant to the provisions of , the undersigned hereby files its notice of satisfaction of lien statement and hereby releases its lien(s), filed with the Clerk of County on the day of , 20 , commencing at Page of Book . W.S. 29-1-313 Dated this day of , 20 . Name of lien claimant: By: Signature: Title: Note to Notarial Officer: If the lien claimant is a legal entity formed under Title 17 of the Wyoming Statutes or other applicable law, use the first jurat. If the lien claimant is an individual or sole proprietor, use the second jurat. (Alternative 1:) STATE OF COUNTY OF ss. On this day of , 20 , subscribed and sworn to before me personally appeared (name of signatory), to me personally known, who has read the foregoing Notice of Satisfaction of Lien and knows the contents thereof and the facts are true to the best of his/her knowledge, and being by me duly sworn, did state that he/she is the (title, position or type of authority granted by lien claimant) of (lien claimant) and that this Notice of Satisfaction of Lien was signed and sealed on behalf of the lien claimant by authority granted to the signatory by the lien claimant. Witness my hand and official seal. Notarial officer My Commission Expires: Seal: (Alternative 2:) STATE OF COUNTY OF ss. On this day of , 20 , subscribed and sworn to before me personally appeared (name of signatory), to me personally known, who has read the foregoing Notice of Satisfaction of Lien and knows the contents thereof and the facts are true to the best of his/her knowledge, and being by me duly sworn, did state that the Notice of Satisfaction of Lien to be the free act and deed of the lien claimant. Witness my hand and official seal. Notarial officer My Commission Expires: Seal: Click to view

History. Laws 2010, ch. 92, § 1.

Editor's notes. —

There is no subsection (b) in this section as it appears in the printed acts.